As filed with the Securities and Exchange Commission on September 18, 2020

Registration No. 333-248658

SECURITIES AND EXCHANGE COMMISSION

WASHINGTON, D.C. 20549

Amendment No. 1

to

FORM F-1

REGISTRATION STATEMENT

UNDER

THE SECURITIES ACT OF 1933

Chindata Group Holdings Limited

(Exact name of Registrant as specified in its charter)

Not Applicable

(Translation of Registrant’s name into English)

No. 47 Laiguangying East Road,

Chaoyang District, Beijing, 100012

The People’s Republic of China

+86 400-879-7679

(Address, including zip code, and telephone number, including area code, of Registrant’s principal executive offices)

Cogency Global Inc.

122 East 42nd Street, 18th Floor

New York, NY10168

+1 800-221-0102

(Name, address, including zip code, and telephone number, including area code, of agent for service)

Copies to:

Approximate date of commencement of proposed sale to the public: as soon as practicable after the effective date of this registration statement.

If any of the securities being registered on this Form are to be offered on a delayed or continuous basis pursuant to Rule 415 under the Securities Act of 1933, check the following box.  ☐

If this Form is filed to register additional securities for an offering pursuant to Rule 462(b) under the Securities Act, check the following box and list the Securities Act registration statement number of the earlier effective registration statement for the same offering.  ☐

If this Form is a post-effective amendment filed pursuant to Rule 462(c) under the Securities Act, check the following box and list the Securities Act registration statement number of the earlier effective registration statement for the same offering.  ☐

If this Form is a post-effective amendment filed pursuant to Rule 462(d) under the Securities Act, check the following box and list the Securities Act registration statement number of the earlier effective registration statement for the same offering.  ☐

Indicate by check mark whether the registrant is an emerging growth company as defined in Rule 405 of the Securities Act of 1933.

Emerging growth company  ☒

If an emerging growth company that prepares its financial statements in accordance with U.S. GAAP, indicate by check mark if the registrant has elected not to use the extended transition period for complying with any new or revised financial accounting standards† provided pursuant to Section 7(a)(2)(B) of the Securities Act.  ☐

† The term “new or revised financial accounting standard” refers to any update issued by the Financial Accounting Standards Board to its Accounting Standards Codification after April 5, 2012.

CALCULATION OF REGISTRATION FEE

The Registrant hereby amends this Registration Statement on such date or dates as may be necessary to delay its effective date until the Registrant shall file a further amendment which specifically states that this Registration Statement shall thereafter become effective in accordance with Section 8(a) of the Securities Act of 1933, as amended, or until the Registration Statement shall become effective on such date as the Securities and Exchange Commission, acting pursuant to such Section 8(a), may determine.

The information in this preliminary prospectus is not complete and may be changed. We may not sell these securities until the registration statement filed with the Securities and Exchange Commission is effective. This preliminary prospectus is not an offer to sell these securities and we are not soliciting any offer to buy these securities in any jurisdiction where such offer or sale is not permitted.

PRELIMINARY PROSPECTUS (Subject to Completion)

Dated             , 2020

American Depositary Shares

Chindata Group Holdings Limited

Representing             Class A Ordinary Shares

This is an initial public offering of American depositary shares, or ADSs, representing Class A ordinary shares of Chindata Group Holdings Limited. We are offering a total of                ADSs. Each ADS represents                of our Class A ordinary shares, par value US$0.00001 per share. [The selling shareholders identified in this prospectus are offering an additional ADSs. We will not receive any of the proceeds from the sale of the ADSs being sold by the selling shareholders.] The underwriters may also purchase up to                ADSs within 30 days from the date of this prospectus.

Prior to this offering, there has been no public market for the ADSs or our ordinary shares. We anticipate the initial public offering price per ADS will be between US$        and US$        . We have applied for the listing of the ADSs representing our Class A ordinary shares on the Nasdaq Global Select Market (“Nasdaq”) under the symbol “CD.”

Neither the United States Securities and Exchange Commission nor any other regulatory body has approved or disapproved of these securities or passed upon the adequacy or accuracy of this prospectus. Any representation to the contrary is a criminal offense.

We are an “emerging growth company” under the applicable U.S. federal securities laws and are eligible for reduced public company reporting requirements. See “Risk Factors” beginning on page 19 for factors you should consider before investing in the ADSs.

Upon the completion of this offering, we will be a ‘‘controlled company’’ as defined under the Nasdaq Stock Market Rules. BCPE Bridge Cayman, L.P. , BCPE Stack Holdings, L.P. and BCPE Stack ESOP Holdco Limited, which we refer to as the Bain Capital Entities, will hold             % of the voting power for the election of directors, immediately upon the completion of this offering. See ‘‘Principal [and Selling] Shareholders.’’

Upon the completion of this offering, our outstanding shares will consist of                  Class A ordinary shares and [391,875,338] Class B ordinary shares. Mr. Jing Ju, our founder, director and chief executive officer, and Bain Capital Entities, will beneficially own all of our then issued Class B ordinary shares and will be able to exercise                 % of the total voting power of our issued and outstanding shares assuming no exercise of the underwriters’ option to purchase additional ADSs, or                 % assuming that the option to purchase additional ADSs is exercised in full. Holders of Class A ordinary shares and Class B ordinary shares have the same rights except for voting and conversion rights. Each Class A ordinary share is entitled to one vote, and each Class B ordinary share is entitled to 15 votes and is convertible into one Class A ordinary share at any time by the holders thereof. Class A ordinary shares are not convertible into Class B ordinary shares under any circumstances. In addition, all of the Class B ordinary shares held by certain Bain Capital Entities (namely, BCPE Bridge Cayman, L.P. and BCPE Stack Holdings, L.P.) shall be automatically and immediately converted into an equal number of Class A ordinary shares on the earlier of (i) such date when the number of ordinary shares held by them and their affiliates (taken as a whole) falls below 10% of our aggregate number of ordinary shares then outstanding and (ii) five years from the date of this offering.

PRICE US$        PER ADS

The underwriters expect to deliver the ADSs against payment in U.S. dollars in New York, New York on             , 2020.

Prospectus dated             , 2020

TABLE OF CONTENTS

You should rely only on the information contained in this prospectus or in any related free writing prospectus that we have filed with the Securities and Exchange Commission, or the SEC. We have not authorized anyone to provide you with information different from that contained in this prospectus or in any related free writing prospectus. We[ and the selling shareholders] are offering to sell, and seeking offers to buy the ADSs offered hereby, but only under circumstances and in jurisdictions where offers and sales are permitted. The information contained in this prospectus is current only as of the date of this prospectus, regardless of the time of delivery of this prospectus or of any sale of the ADSs.

Neither we nor any of the underwriters has taken any action that would permit a public offering of the ADSs outside the United States or permit the possession or distribution of this prospectus or any filed free writing prospectus outside the United States. Persons outside the United States who come into possession of this prospectus or any filed free writing prospectus must inform themselves about, and observe any restrictions relating to, the offering of the ADSs and the distribution of this prospectus or any filed free writing prospectus outside the United States.

Until             , 2020 (the 25th day after the date of this prospectus), all dealers that buy, sell or trade ADSs, whether or not participating in this offering, may be required to deliver a prospectus. This is in addition to the obligation of dealers to deliver a prospectus when acting as underwriters and with respect to their unsold allotments or subscriptions.

i

1

2

3

4

5

6

7

8

9

10

11

12

13

14

15

16

17

18

Risk Factors

You should consider carefully all of the information in this prospectus, including the risks and uncertainties described below and our consolidated financial statements and related notes, before making an investment in the ADSs. Any of the following risks and uncertainties could have a material adverse effect on our business, financial condition and results of operations. The market price of the ADSs could decline significantly as a result of any of these risks and uncertainties, and you may lose all or part of your investment. When determining whether to invest, you should also refer to the other information contained in this prospectus, including our financial statements and the related notes thereto. You should also carefully review the cautionary statements referred to under “Forward-looking Statements.” Our actual results could differ materially and adversely from those anticipated in this prospectus.

Risks Relating to Our Business and Industry

We may not be able to effectively manage our growth of our business as we expand our operations, which could negatively impact our business and financial performance.

We have experienced significant growth in recent years. Our revenues grew from RMB98.5 million in 2018 to RMB853.0 million (US$120.7 million) in 2019 and increased from RMB221.5 million for the six months ended June 30, 2019 to RMB810.6 million (US$114.7 million) for the six months ended June 30, 2020. We derive revenues primarily from our data center colocation services and, to a lesser extent, data center colocation rental. We plan to further increase our service capacities through increasing the number and size of the data center campuses and facilities that we operate, and thus will be required to commit a substantial amount of operating and financial resources. If we are not able to generate sufficient operating cash flows or obtain third-party financing, our ability to fund our expansion plans may be limited. See “—Development of data centers is capital intensive. We may not be able to generate sufficient capital or obtain additional capital to meet our future capital needs, on favorable terms or at all, which may lead to significant disruption to our business and adversely affect our financial position.”

Our rapid growth has placed, and will continue to place, significant demands on our management and our administrative, operational and financial systems. Continued expansion exposes us to additional challenges, including:

19

Moreover, we may not have sufficient client demand in the markets where our data centers are located. We may overestimate the demand for our services and as a result may increase our data center capacity or expand our network more aggressively than needed, resulting in a negative impact to our results of operations.

We may expand into geographic areas where we do not have experience with local regulations or regulators or where local market conditions are unfavorable for our business. We may not be able to effectively attract clients in the new markets to generate sufficient revenues and offset the costs incurred by the expansion, which could negatively impact our financial performance and prospects.

If we fail to manage the growth of our operations effectively, our businesses and results of operations may be materially and adversely affected.

Development of data centers is capital intensive. We may not be able to generate sufficient capital or obtain additional capital to meet our future capital needs, on favorable terms or at all, which may lead to significant disruption to our business expansion and adversely affect our financial position.

Constructing and developing data centers are capital intensive. We are required to fund the costs of constructing and developing our data centers with cash deriving from operations, as well as from financing from banks, other borrowings and capital markets. Moreover, such costs have increased in recent years, and may further increase in the future, which may make it more difficult for us to expand our business and to remain profitable. There can be no assurance that our future revenues would be sufficient to offset increases in these costs, or that our business operations will generate capital sufficient to meet our anticipated capital requirements. If increase in our future revenues would not be sufficient to offset the increased costs, or we cannot generate sufficient capital to meet our anticipated capital requirements, our financial condition, business expansion and future prospects could be materially and adversely affected.

To fund our future growth, we may need to raise additional funds through equity or debt financing in the future in order to meet our operating and capital needs, which may not be available on favorable terms, or at all. If we raise additional funds through issuances of equity or equity-linked securities, our existing shareholders could suffer significant dilution in their ownership percentage of our company, and any new equity securities we issue could have rights, preferences, and privileges senior to those of holders of our ordinary shares. In addition, any debt financing that we may obtain in the future could have restrictive covenants relating to our capital raising activities and other financial and operational matters, which may make it more difficult for us to obtain additional capital and to pursue business opportunities, including potential acquisitions. Our inability to obtain additional debt and/or equity financing or to generate sufficient cash from operations may require us to prioritize projects or curtail capital expenditures and could adversely affect our results of operations.

The market in which we participate is competitive. Failure to compete effectively may result in loss of our market share and a decrease in our revenues and profitability.

We compete with a wide range of data center solution providers in the markets we participate. Some of our current and future competitors may have advantages over us, including greater name recognition, longer

20

operating histories, pre-existing relationships with current or potential clients, significantly greater financial, marketing and other resources and more ready access to capital, all of which allow them to offer competitive prices and respond more quickly to new or changing opportunities. Many of these competitors own properties similar to ours in the same markets in which our properties are located, or in markets where the cost to operate a data center is less than the costs to operate our data centers. Many of our competitors and new entrants to the data center market are developing additional data center space in the markets that we serve.

We face pricing pressure for our services. Prices for our services are affected by a variety of factors, including supply and demand conditions and pricing pressures from our competitors. A buildup of new data centers or reduced demand for data center services could result in an oversupply of data center space in the markets where we operate. Excess data center capacity could cause downward pricing pressure and limit the number of economically attractive markets that are available to us for expansion, which could negatively impact our business and results of operations. In addition, our competitors may offer services that are more competitively priced compared to ours. We may be required to lower our prices to remain competitive, which may decrease our margins and adversely affect our business prospects, financial condition and results of operations.

We will also face increased competition as we expand our operations, and our competitors in new markets we expand into may have more experience than us in operating in those markets. If we fail to compete effectively, our business, financial performance and prospects will be materially and adversely affected.

Our revenues are highly dependent on a limited number of major clients, and the loss of any such client or any other significant client, or the inability of any such client or any other significant client to make payments to us as due, could have a material adverse effect on our business, results of operations and financial condition.

We have in the past derived, and believe that we will continue to derive, a significant portion of our revenues from a limited number of clients. Revenues from ByteDance accounted for 68.2% and 81.6% of our total revenues in 2019 and for the six months ended June 30, 2020. Revenues from Wangsu, a related party, accounted for 11.1% and 7.1% of our total revenues in 2019 and for the six months ended June 30, 2020. No other client accounted for 10% or more of our total revenues in 2019 and for the six months ended June 30, 2020. As a hyperscale data center solution provider, we expect our revenues will continue to be highly dependent on a limited number of clients who account for a large percentage of our contractually committed capacity. Moreover, for several of our data centers, a limited number of clients accounted for substantial majority of our contractually committed capacity. If one or more of our significant clients fail to make payments to us or does not honor their contractual commitments, our revenues and results of operations would be materially and adversely affected. In addition, the contracts we enter into with our significant clients typically provide that they have early termination options, subject to payment of specified early termination fees that equal to a substantial amount of the total services fees. The amount of such early termination fee depends on the length of the duration of the contract that has expired, and is usually less than the revenues we would expect to receive under a given contract. If any of our significant clients exercises any applicable early termination options or we are unable to renew our existing contracts with them on similar terms or at all, and we are unable to find new clients to utilize the space to be vacated in a timely manner or at the same fee levels, our results of operations will be adversely affected. For example, certain of our agreements with Wangsu will expire in 2021, and we may not be able to renew them at favorable terms to us, or at all. As of the date of this prospectus, none of our clients have exercised their early termination options which we believe would have a material adverse effect on our business, results of operations and financial condition. However, we cannot provide any assurance that they will not do so in the future.

There are a number of factors that could cause us to lose major clients. Because many of our contracts involve services that are mission-critical to our clients, any failure by us to meet a client’s expectations could result in cancellation or non-renewal of the contract. Our contracts usually allow our clients to terminate their contracts with us before the end of the contract period under certain specified circumstances, including our

21

failure to deliver services as required under such agreements, and in some cases without cause as long as sufficient notice and early termination fee is given. In addition, our clients may decide to reduce spending on our services in response to a challenging economic environment or other factors, both internal and external, relating to their business such as corporate restructuring or changing their outsourcing strategy by moving more facilities in-house or outsourcing to other service providers. Some of our clients may choose to develop or expand their own data center facilities in the future, which may result in a decline in our existing or potential clients.

In addition, our reliance on any individual significant client may give that client a degree of pricing leverage against us when negotiating contracts and terms of services with us. The loss of any of our major clients, or a significant decrease in the extent of the services that they outsource to us or the level of prices we offer, could materially and adversely affect our financial condition and results of operations.

Any of our clients could experience a downturn in their business, which in turn could result in their inability or failure to make timely payments to us pursuant to their contracts with us. In the event of any client default, our liquidity could be adversely impacted and we may experience delays in enforcing our rights and may incur substantial costs in protecting our investment. These risks would be particularly significant if one of our major clients were to experience adverse effects to its business and defaults under their contracts with us. The inability of any significant client to meet its payment obligations could impact us negatively and significantly.

Our business, results of operations and financial condition may be adversely affected if our largest client were to experience adverse effects to its business as a result of the executive orders issued by the U.S. President.

In August 2020, U.S. President Donald J. Trump issued two executive orders related to ByteDance, our largest client in terms of revenue contribution in 2019 and for the six months ended June 30, 2020, accounting for 68.2% and 81.6% of our total revenues, respectively. One of the executive orders dated August 6, 2020 (the “August 6 Executive Order”) prohibits certain unspecified transactions between ByteDance Ltd. or its subsidiaries and any person subject to U.S. jurisdiction, while the other executive order dated August 14, 2020 enjoins that ByteDance Ltd. shall divest all interest and rights in any tangible or intangible assets or property used to enable or support its operation of the TikTok application and any data obtained or derived from the TikTok application in the United States and prohibits its ownership of Musical.ly in the United States. Either or both of these executive orders could have a negative impact on ByteDance’s business prospects. In addition, the U.S. Department of Commerce is directed to specify the types of “transactions” that will be subject to the first of these two executive orders by September 20, 2020. On September 18, 2020, the U.S. Department of Commerce published the restrictions that are applicable to the TikTok application pursuant to the August 6 Executive Order, which, among other things, prohibit any provision of services to distribute or maintain the TikTok application, constituent code, or application updates through an online mobile application store in the United States effective as of September 20, 2020, and, as of November 12, 2020, prohibit certain other provision of services enabling the functioning or optimization of, and certain utilization of, the TikTok U.S. application. The publication further provides that the U.S. Department of Commerce may further implement restrictions under authority of the August 6 Executive Order, but that otherwise any other transaction with ByteDance Ltd. or its subsidiaries is permitted unless identified as prohibited or otherwise contrary to law. Although all of our business with ByteDance is based in China and for its operations in China only, as there are uncertainties regarding the interpretation and guidance to be issued by the U.S. Department of Commerce, there is no assurance that we would not be treated as a person or entity subject to U.S. jurisdiction, or that we would not be prohibited from entering into any transaction with ByteDance pursuant to the executive order or future restrictions that may be issued by the U.S. Department of Commerce or other U.S. regulators. Should ByteDance cancel substantial projects or otherwise significantly reduce its volume of business with us as a result of the executive orders, our revenues and profitability would be materially reduced and our business and results of operations would be seriously harmed.

If we do not succeed in attracting new clients for our services and/or growing revenues from existing clients, our business and results of operation may be adversely affected.

We have been expanding our client base to cover a range of industry verticals, particularly cloud service providers and technology companies. Our ability to attract new clients, as well as our ability to grow revenues

22

from our existing clients, depends on a number of factors, including our data center capacity, our ability to offer high-quality services at competitive prices, the strength of our competitors and the capabilities of our client acquisition team to attract new clients. If we fail to attract new clients, we may not be able to grow our revenue as quickly as we anticipate or at all.

In addition, as our client base grows and diversifies into other industries, we may be unable to provide services that cater to their changing needs, which could result in client dissatisfaction, decreased overall demand for our services and loss of expected revenues. Moreover, our inability to meet client expectations may damage our reputation and could consequently limit our ability to retain existing clients and attract new clients, which would adversely affect our ability to generate revenues and negatively impact our results of operations.

Factors that adversely affect the industries in which our clients operate or information technology spending in these industries, particularly in the Internet and cloud service industries, may adversely affect our business.

Our clients are primarily technology companies in the Internet, cloud, software and other technology-based industries. Our clients, some of whom have experienced rapid changes in their business, substantial price competition and pressures on their profitability, may request price reductions or decrease their demand for space in our data centers, which could harm our financial performance. Furthermore, a decline in the technology industry or the demand for cloud-based services, or the desire of any of these companies to outsource their data center needs, could lead to a decrease in the demand for space in our data centers, which would have an adverse effect on our business and financial condition. We also are susceptible to adverse developments in the industries in which our clients operate, such as decreases in demand for their products or services, business layoffs or downsizing, industry slowdowns, relocations of businesses, costs of complying with government regulations or increased regulation and other factors. We also may be materially adversely affected by any downturns in the market for data centers due to, among other things, oversupply of or reduced demand for space or a slowdown in the technology industry. Also, a lack of demand for data center space by enterprise clients could have a material adverse effect on our business, results of operations and financial condition. If any of these events happen, we may lose clients or have difficulties in selling our services, which would materially and adversely affect our business and results of operations.

We generate a significant portion of our revenues from a small number of data centers, with some located in close proximity to each other. A significant disruption in any of such data centers could materially and adversely affect our business, results of operations and financial condition.

We generate significant revenues from a small number of hyperscale data center campuses located in close proximity to each other and a significant disruption to any single location could materially and adversely affect our operations. Our data centers typically surround metropolitan areas such as Beijing, Shanghai, Shenzhen, Kuala Lumpur and Mumbai and are in proximity to the corporate headquarters of our clients. The occurrence of a catastrophic event, or a prolonged disruption in any of these regions, could materially and adversely affect our operations.

We have a limited operating history as a combined company after the recent merger of Chindata and Bridge Data Centres. We may face challenges integrating our operations, services and personnel and may be unable to achieve the anticipated synergies from the combination. Our historical operating and financial results may not be indicative of future performance, which makes it difficult to predict our future business prospects and financial performance.

The combination of our China and overseas operations were completed in 2019. We have a limited operating history and experience in our business operation as a combined company, which makes it difficult to evaluate our future prospects and ability to make profit. Our ability to realize the anticipated benefits of the combination depends, to a large extent, on our ability to integrate independent businesses, which can be a complex, costly and time-consuming process, and thus requires significant time and focus from our management team and may divert attention from the day-to-day operations of our business. In addition, even if the operations of Chindata and Bridge Data Centres are integrated successfully, we may not realize the full benefits of the combination, including the synergies, operating efficiencies, or sales or growth opportunities that are expected.

23

In addition, the overall integration of the businesses may result in material unanticipated problems, expenses, liabilities, competitive responses and loss of client relationships, among other potential adverse consequences. If we cannot integrate and operate acquired properties or businesses to meet our financial expectations, our financial condition, results of operations, cash flow and ability to satisfy our debt service obligations could be materially adversely affected.

If we are unable to locate and secure suitable sites for additional data centers on commercially acceptable terms, our ability to grow our business may be limited.

The selection of land or facilities suitable for development of data centers is a critical factor in our expansion plans. The available capacity and land resources that we hold may not be able to satisfy the growing demand of our clients. There may not be suitable properties available in our markets with the necessary combination of high power capacity and fiber connectivity, or selection of such sites may be limited. For instance, it may not always be possible to locate new data center facilities adjacent to our existing locations, which is our preference. Our lack of operating experience in a new market may make it difficult for us to successfully identify and acquire suitable properties in these markets in locations that are attractive to our clients and that have access to multiple network providers and a significant supply of electrical power. Any inability to acquire additional sites for development, at all or on terms commercially acceptable to us, could have a material adverse effect on our growth, future results of operations and financial condition.

We face risks associated with having a long selling, construction and implementation cycle for our services that requires us to make significant capital expenditures and resource commitments prior to receiving payments for those services.

Our industry for hyperscale data centers is characterized by a relatively long selling, construction and implementation cycle, which typically ranges from 15 to 19 months and requires significant investment of capital, human resources and time. Constructing, developing and operating our data centers require significant capital expenditures. A client’s decision to utilize our colocation services or our other services typically involves time-consuming contract negotiations regarding the service level commitments and other terms, and substantial due diligence on the part of the client regarding the adequacy of our infrastructure and attractiveness of our resources and services. Our efforts in pursuing a particular sale or client may not be successful, and we may not always have sufficient capital on hand to satisfy our working capital needs. If our efforts in pursuing sales and clients are unsuccessful, or our cash on hand is insufficient to cover our working capital needs over the course of our long selling cycle, our financial condition could be negatively affected.

Delays in the construction of new data centers or the expansion of existing data centers could involve significant risks to our business.

In order to meet client demand and the continued growth of our business, we need to expand existing data centers, develop new facilities or obtain suitable land to build new data centers. Expansion of existing data centers and construction of new data centers are currently underway, or being contemplated and such expansion and construction require us to carefully select and rely on the experience of contractors during the construction process. We endeavor to engage contractors with a strong reputation and proven track record, high-performance reliability and adequate financial resources. However, any such contractor may still fail to provide satisfactory services at the level of quality required by us. Furthermore, if a contractor experiences financial or other problems during the design or construction process, we could experience significant delays and/or incur increased costs to complete the projects, resulting in negative impacts on our results of operations.

In addition, we need to work closely with local power and network suppliers where our proposed data centers are located. We also rely on certain key technical personnel, such as engineering firms and construction contractors capable of developing our projects, and key suppliers of electrical and mechanical equipment. Delays in actions that require the assistance of such third parties, or delays in receiving required permits and approvals from local governments, which are out of our control, may also affect the construction and development of new projects or result in them not being completed at all.

24

Furthermore, the measures taken by the Chinese, Malaysian and Indian governments to contain the spread of COVID-19 in early 2020 delayed the return of our employees to work, and thus affected the construction and development of our new projects. See “—The outbreak of COVID-19 could disrupt our operations and construction projects and adversely affect our results of operations” for more information about the impact of the COVID-19 outbreak on us.

If we experience significant delays in the supply of power required to support the data center expansion or new construction, either during the design or construction phases, the progress of the data center expansion and/or construction could deviate from our original plans, which could cause material and negative effect to our revenue growth, profitability and results of operations.

Limited availability of power and power outages may adversely affect our results of operation.

We are a large consumer of power and costs of power account for a significant portion of our cost of revenues. We require power supply to provide many services we offer, such as powering and cooling our clients’ servers and network equipment and operating critical data center plant and equipment infrastructure. We are subject to risks associated with obtaining access to a sufficient amount of power from local utilities and constraints on the amount of electricity that a particular locality’s power grid is capable of providing at any given time.

In addition, the amount of power required by our clients may increase as they adopt new technologies, for example, for virtualization of hardware resources, or grow their businesses. As a result, our clients’ average amount of power utilized per server is increasing, which in turn increases power consumption required to cool the data center facilities. Although we aim to improve the energy efficiency of the data center facilities that we operate, such facilities may not be able to provide sufficient power to meet the growing needs of our clients. In addition, we may not be able to maintain competitive PUE for our data centers in service. Our clients’ demand for power may exceed the power capacity in our data centers, which may limit our ability to fully utilize the capacity of these data centers. We may lose clients or our clients may reduce the services purchased from us due to limited availability of power resources, or we may incur costs for data center capacity which we cannot utilize, which would reduce our revenues and have a material and adverse effect on our cost of revenues and results of operations.

In addition, we attempt to limit exposure to system downtime due to power outages from the electric grid by using backup generators and battery power. However, these protections may not limit our exposure to power shortages or outages entirely. Any system downtime resulting from insufficient power resources or power outages could damage our reputation and lead us to lose current and potential clients, which would harm our financial condition and results of operations.

Increased telecommunication costs and any delays or disruptions in Internet connectivity to our data centers may adversely affect our operating results.

Our clients require connectivity to the fiber networks of multiple telecommunication carriers, and we depend upon the presence of telecommunication carriers’ fiber networks serving the locations of our data centers in order to attract and retain clients. Any carrier may elect not to offer its services within our data centers, and any carrier that has decided to provide Internet connectivity to our data centers may discontinue the provision of Internet connectivity to our data centers. If carriers were to consolidate or otherwise downsize or terminate connectivity within our data centers, such action could have an adverse effect on the businesses of our clients and, in turn, our own business, financial condition and results of operations.

Each new data center that we develop requires the construction and operation of a sophisticated redundant fiber network. The construction required to connect multiple carrier facilities to our data centers is complex and involves factors outside of our control, including regulatory requirements and the availability of construction resources. If we are not able to establish adequate Internet connectivity to our data centers, such connectivity is materially delayed, interrupted or is discontinued, or there are significant hardware or fiber failures on this network, our ability to attract and retain new clients or retain existing clients could be impacted negatively, which in turn could have a material adverse effect on our business, financial condition and results of operations.

25

As our client base grows and their usage of telecommunications capacity increases, we may be required to make additional investments in our capacity to maintain adequate data transmission speeds. The availability of such capacity may be limited or the costs may be on terms unacceptable to us. If adequate capacity is not available to us as our clients’ usage increases, our network may be unable to achieve or maintain sufficiently high data transmission capacity, reliability or performance. In addition, our operating margins will suffer if our bandwidth suppliers increase the prices for their services and we are unable to pass along the increased costs to our clients.

If we are unable to adapt to new technologies or industry standards in a timely and cost-effective manner, our business, financial performance and prospects could be materially and adversely affected.

The markets for the data centers we own and operate, as well as certain of the industries in which our clients operate, are characterized by rapidly changing technologies, evolving industry standards, and frequent new service introductions. As a result, the infrastructure at our data centers may become obsolete or unmarketable due to demand for new processes and technologies, including, new processes to deliver power to, or eliminate heat from, computer systems and new technology that permits higher levels of critical load and heat removal than our data centers are currently designed to provide. In addition, the systems that connect our data centers to the Internet and other external networks may become outdated, including with respect to latency, reliability and diversity of connectivity. When clients demand new processes or technologies, we may not be able to upgrade our data centers on a cost-effective basis, or at all, due to, among other things, increased expenses to us that cannot be passed on to clients or insufficient revenues to fund the necessary capital expenditures. The obsolescence of our power and cooling systems and/or our inability to upgrade our data centers, including associated connectivity, could reduce revenues at our data centers and could have a material adverse effect on us. To be successful, we must adapt to our rapidly changing market by continually improving the performance, features and reliability of our services and modifying our business strategies accordingly, which could cause us to incur substantial costs. We may not be able to adapt to changing technologies in a timely and cost-effective manner, if at all, which would adversely impact our ability to sustain and grow our business. If we are unable to purchase the hardware or obtain a license for the software that our services depend on, our business could be significantly and adversely affected.

Furthermore, potential future regulations that apply to industries we serve may require clients in those industries to seek specific requirements from their data centers that we are unable to provide. If such regulations were adopted, we could lose clients or be unable to attract new clients in certain industries, which could have a material adverse effect on us.

In addition, new technologies or industry standards have the potential to replace or provide lower cost alternatives to our services. We focus primarily on providing data center solutions through hyperscale data centers. We cannot guarantee that we will be able to identify the emergence of all the new service alternatives successfully, modify our services accordingly, or develop and bring new services to market in a timely and cost-effective manner to address these changes. If and when we do identify the emergence of new service alternatives and introduce new services to market, those new services may need to be made available at lower profit margins than our then-current services. Failure to provide services to compete with new technologies or the obsolescence of our services could lead us to lose current and potential clients or could cause us to incur substantial costs, which would harm our operating results and financial condition. Our introduction of new alternative services that have lower price points than our current offerings may also result in our existing clients switching to the lower cost products, which could reduce our revenues and have a material adverse effect on our results of operation.

Any significant or prolonged failure in the data center facilities we operate or services we provide, including events beyond our control, would lead to significant costs and disruptions and would reduce the attractiveness of our facilities, harm our business reputation and have a material adverse effect on our results of operation.

The data center facilities we operate are subject to failure. Any significant or prolonged failure in any data center facility we operate or services that we provide, including a breakdown in critical plant, equipment or

26

services, such as the cooling equipment, generators, backup batteries, routers, switches, or other equipment, power supplies, or network connectivity, whether or not within our control, could result in service interruptions and data losses for our clients as well as equipment damage, which could significantly disrupt the normal business operations of our clients and harm our reputation and reduce our revenues. Any failure or downtime in one of the data center facilities that we operate could affect many of our clients. The total destruction or severe impairment of any of the data center facilities we operate could result in significant downtime of our services and catastrophic loss of client data. Since our ability to attract and retain clients depends on our ability to provide highly reliable service, even minor interruptions in our service could harm our reputation and cause us to incur financial penalties. The services we provide are subject to failures resulting from numerous factors, including, but not limited to, human error or accident, natural disasters and security breaches, whether accidental or willful.

We may in the future experience interruptions in service, power outages and other technical failures or be otherwise unable to satisfy the requirements of the agreements we have with clients for reasons outside of our control. As our services are critical to many of our clients’ business operations, any significant or prolonged disruption in our services could result in lost profits or other indirect or consequential damages to our clients and subject us to lawsuits brought by the clients for potentially substantial damages. Furthermore, these interruptions in service, regardless of whether they result in breaches of the agreements we have with clients, may negatively affect our relationships with clients and lead to clients terminating their agreements with us or seeking damages from us or other compensatory actions. We have taken and continue to take steps to improve our infrastructure to prevent service interruptions and satisfy the requirements of the agreements we have with clients, including upgrading our electrical and mechanical infrastructure and sourcing, designing the best facilities possible and implementing rigorous operational procedures to maintenance programs to manage risk. Service interruptions continue to be a significant risk for us and could affect our reputation, damage our relationships with clients and materially and adversely affect our business. Any breaches of the agreements we have with clients will damage our relationships with clients and materially and adversely affect our business.

We rely on suppliers for project construction, equipment procurement and installation and general operations of our business.

We contract with third parties for the supply of components and services needed in our projects, such as construction works and equipment, that we use in the provision of our services to our clients. If we are unable to find a qualified new supplier in a timely manner, the loss of a significant supplier could delay expansion of the data center facilities that we operate, impact our ability to sell our services and increase our costs. In addition, if our existing suppliers are unable to provide products and services that meet evolving industry standards or that are unable to effectively interoperate with other products or services that we use, we may be forced to look for new suppliers on favorable terms or at all. As a result, we may be unable to meet all or a portion of our client service commitments, which could materially and adversely affect our results of operations.

Failure to accurately estimate the resources and time required for the fulfillment of our obligations under these contracts could negatively affect our results of operation.

Our contract terms require us to undertake significant projections and planning related to resource utilization and costs. Power costs may be included in the costs for our solutions, or we may charge our clients separately for actual power consumed. The contracts with our clients typically have fixed price based on capacity. Although our past project experience helps to reduce the risks associated with estimating, planning and performing fixed-price contracts, we bear the risk of failing to accurately estimate our projected costs, including power costs as we may not accurately predict our client’s ultimate power usage once the contract is implemented. Increases in power costs may directly affect our profitability. There can be no assurance that we will be able to reduce the risk of estimating, planning and performing our contracts. Any failure to accurately estimate the resources and time required for a project, or any other factors that may impact our costs, could adversely affect our profitability and results of operations.

27

The contract commitments of our clients are subject to reduction and potential cancellation and we may be unable to achieve high contract renewal rates.

Many of our client contracts allow for early termination, subject to payment of early termination fee, which may be less than the revenues we would expect to receive under such contracts. Any penalty for early termination may not adequately compensate us for the time and resources we have expended in connection with such contract, or at all, which could have a material adverse effect on our results of operations and cash flows. Reduced client contract commitments could also put pressure on our pricing. In addition, our client contract commitments during a particular future period may be reduced for reasons outside of our clients’ control, such as general current economic conditions. If our client contract commitments are significantly reduced, our business, financial condition and results of operations could be materially and adversely affected.

Even if our current and future clients have entered into a binding contract with us, they may choose to terminate such contract prior to the expiration of its terms. There are a number of factors that could cause us to lose clients. Our contracts usually allow our clients to terminate their contracts with us before the end of the contract period under certain specified circumstances, including our failure to deliver services as required under such agreements, and in some cases without cause as long as sufficient notice and early termination fee is given. In addition, our clients may decide to reduce spending on our services in response to a challenging economic environment or other factors, both internal and external, relating to their business such as corporate restructuring or changing their outsourcing strategy by moving more facilities in-house or outsourcing to other service providers. Some of our clients may choose to develop or expand their own data center facilities in the future, which may result in a decline in our existing or potential clients.

We seek to renew client contracts when those contracts are due for renewal. We endeavor to provide high levels of client service, support, and satisfaction to maintain long-term relationships and to secure high rates of contract renewals for our services. Nevertheless, we cannot assure you that we will be able to renew service agreements with our existing clients or re-commit space relating to expired service agreements to new clients if our current clients do not renew their contracts. In the event of non-renewal and if we are unable to secure contractual commitments from other sources in a timely manner, our results of operations will be adversely impacted.

We are in the process of expanding our operations into new geographies in the Asia-Pacific emerging markets, which exposes us to significant additional regulatory, economic and political risks due to our unfamiliarity with those areas, the failure to handle which may adversely affect our business, results of operations and financial condition.

We currently operate in China, Malaysia and India, and plan to expand our data center development and operations into new geographies in the Asia-Pacific emerging markets. As a part of this expansion strategy, we may develop and operate data centers in markets in which we have little or no operating experience, and thus will be exposed to significant additional regulatory, economic and political risks. Our ability to successfully enter new markets will depend on, among other things, our ability to identify and acquire land suitable for development, our ability to develop new data centers on our anticipated time-line and at the expected costs, and our ability to secure new client commitments. Our new markets may have different competitive conditions, and may subject us to operating considerations that are different from those we have experienced in our existing markets, which, in turn, may adversely affect our ability to develop and operate data centers in these new markets.

Expansion of our business into new markets will involve substantial planning and allocation of significant company resources and certain risks, including risks related to financing, zoning, regulatory approvals, construction costs and delays. Our lack of operating experience in these new markets may adversely impact our ability to successfully develop new data center facilities in such markets. In order to successfully develop our prospective data center facilities in these new markets, we need to work closely with local power and network

28

suppliers, and sometimes local governments, where our proposed data centers are located and certain key third-party technical personnel, such as engineering firms and construction contractors, with whom we have little or no experience. Should a significant third party working on any such development project experience financial or other material problems or breach their contractual obligations during the construction process, we could experience significant delays, increased costs to complete the project and other issues that may negatively impact our expected financial returns. These and other risks could result in delays to, or increased costs of, completing development projects in new markets or could prevent the completion of development projects in new markets, any of which could have a material adverse effect on our business, financial condition and results of operations.

Due to our lack of operating experience in our new markets, we may be unable to attract new clients on a timely basis, or at all, to the properties that we have developed. Once development of a data center facility is complete, we incur certain operating expenses even if there are no clients occupying any space. Consequently, if any of our properties have significant vacancies for an extended period of time, we will incur operating expenses that will not be reimbursed by clients and our results of operations and business and financial condition will be affected adversely, the impact of which could be material.

We are subject to a variety of national, regional and local laws and regulations in the markets where we do business, currently, China, Malaysia and India, some of which may conflict with each other and all of which are subject to change. These laws and regulations include telecommunication regulations, tax laws and regulations, environmental regulations, labor laws and other government requirements, approvals, permits and licenses. Any new regulations or policies pertaining to our business may result in significant additional expenses to us and clients, which could cause a significant reduction in demand for data center services. Changes in applicable laws or regulations, or in the interpretations of these laws and regulations, could result in increased compliance costs or the need for additional capital expenditures. If we fail to comply with these requirements, we could also be subject to civil or criminal liability and the imposition of fines.

Regulatory changes in a jurisdiction where we are developing data center facilities may make the continued development of the project infeasible or economically disadvantageous and any expenditure that we have previously made on the project may be wholly or partially written off. Any of these changes could significantly increase the regulatory related compliance and other expenses incurred by the projects and could significantly reduce or entirely eliminate any potential revenues that can be generated by one or more of the projects or result in significant additional expenses to us and clients, which could materially and adversely affect our business, financial condition, results of operations and cash flows.

Our indebtedness could adversely affect our ability to raise additional capital to fund our operations and expose us to interest rate risk to the extent of our variable rate debt.

As of June 30, 2020, we had total consolidated indebtedness of RMB4,088.5 million (US$578.7 million), including short-term and long-term banks loans, and finance lease obligations. Our indebtedness could, among other consequences:

29

As a result of covenants and restrictions, we may be unable to raise additional debt or equity financing to compete effectively or to take advantage of new business opportunities. Our current or future borrowings could increase the level of financial risk to us and, to the extent that the interest rates are not fixed and rise, or that borrowings are refinanced at higher rates, our available cash flow and results of operations could be adversely affected.

We have financing arrangements in place with various lenders to support specific data center construction projects. Certain of these financing arrangements are secured by our accounts receivable, property and equipment and land use rights. The terms of these financing arrangements may impose covenants and obligations on the part of both the borrowing subsidiary of ours and us as guarantor. For more information regarding covenants arising from our financing arrangements, see “Management’s Discussion and Analysis of Financial Condition and Results of Operations—Contractual Obligations.” Furthermore, we may lose such assets that we pledge as collateral to secure our debts in the event of default.

The terms of any future indebtedness we may incur could include more restrictive covenants. A breach of any of these covenants could result in a default with respect to the related indebtedness. If a default occurs, the relevant lenders could elect to declare the indebtedness, together with accrued interest and other fees, to be due and payable immediately. This, in turn, could cause our other debt, to become due and payable as a result of cross-default or acceleration provisions contained in the agreements governing such other debt. In the event that some or all of our debt is accelerated and becomes immediately due and payable, we may not have the funds to repay, or the ability to refinance, such debt.

Insurance coverage of our operations may be insufficient, especially in cases of prolonged or extraordinary adverse events. Any losses to our properties that are not covered by insurance, or that exceed our insurance coverage limits, may expose us to significant costs and business disruption.

Our operations are subject to hazards and risks normally associated with the daily operations of data center facilities. Currently we maintain insurance policies for our business operations in line with industry practice. However, our current insurance policies may be insufficient, especially when a prolonged or catastrophic event occurs. If we experience a loss that is uninsured or exceeds policy limits, our business could be disrupted and we could lose the capital invested in the damaged properties as well as the anticipated future cash flows from those properties. These events would materially adversely affect our business, financial condition and results of operations.

Security breaches or alleged security breaches of our data centers could disrupt our operations and have a material adverse effect on our business, financial condition and results of operation.

A security breach of our data center facilities could result in the misappropriation of our or our clients’ proprietary information, and may cause interruptions or malfunctions in our operations or the operations of our clients. As we commit to implementing effective security measures to safeguard our data centers, such a compromise could be particularly harmful to our brand and reputation. We may be required to expend significant capital and resources to protect against such threats or to alleviate problems caused by breaches in security. Security risks and deficiencies may also be identified in the course of government inspections, which could subject us to fines and other sanctions. As techniques used to breach security change frequently and are often not

30

recognized until launched against a target, we may not be able to implement new security measures in a timely manner or, if and when implemented, we may not be certain whether these measures could be circumvented. Any breaches that may occur could expose us to increased risk of lawsuits, regulatory penalties, loss of existing or potential clients, harm to our reputation and increases in our security costs, which could have a material adverse effect on our financial condition and results of operations.

In addition, any assertions of alleged security breaches or systems failure made against us, whether true or not, could harm our reputation, cause us to incur substantial legal fees and have a material adverse effect on our business, reputation, financial condition and results of operations.

Our leases for data centers could be terminated early and we may not be able to renew our existing leases on commercially acceptable terms or our rent or payment under the agreements could increase substantially in the future, which could materially and adversely affect our operations.

We enter into leases for certain of our wholesale and retail data centers. Upon the expiration of such leases, we may not be able to renew these leases on commercially reasonable terms, if at all. Under certain lease agreements, the lessor may terminate the agreement by giving prior notice and paying default penalties to us. However, such default penalties may not be sufficient to cover our losses. Even though the lessors for most of our data centers generally do not have the right of unilateral early termination unless they provide the required notice, the lease may nonetheless be terminated early if we are in material breach of the lease agreements. We may assert claims for compensation against the landlords if they elect to terminate a lease agreement early and without due cause. Although historically we have successfully renewed all agreements we wanted to renew, and we do not believe that any of our agreements will be terminated early in the future, there can be no assurance that the counterparties will not terminate any of our agreements prior to its expiration date. If the leases for our data centers were terminated early prior to their expiration date, notwithstanding any compensation we may receive for early termination of such leases, or if we are not able to renew such leases, or if we are unable to find suitable alternative premises in a timely manner, we may have to incur significant costs related to relocation. Any relocation could also affect our ability to provide continuous uninterrupted services to our customers and harm our reputation. Furthermore, rent or payment under such leases in the future may increase substantially in the future. Any of the foregoing could have an adverse impact on our business and results of operations.

Clients who rely on us for the colocation of their servers could potentially sue us for their lost profits or damages if there are disruptions in our services, which could impair our financial condition.

As our services are critical to many of our clients’ business operations, any significant disruption in our services could result in lost profits or other indirect or consequential damages to our clients. Although some of our client contracts contain provisions attempting to limit our liability for breach of the agreement, there can be no assurance that a court would enforce any contractual limitations on our liability in the event that one of our clients brings a lawsuit against us as the result of a service interruption that they may ascribe to us. The outcome of any such lawsuit would depend on the specific facts of the case and any legal and policy considerations that we may not be able to mitigate. In such cases, we could be liable for substantial damage awards. Since we do not carry liability insurance coverage, such damage awards could seriously impair our financial condition.

We may not be able to prevent others from making unauthorized use of our intellectual property. If we fail to protect our intellectual property rights, our brand and business may suffer.

Our success depends in part upon our propriety intellectual rights, including certain patents, trademarks, domain names, know-how, methodologies, practices, tools and technical expertise that are critical to our business. We primarily rely on a combination of intellectual property laws and contractual arrangements, including confidentiality and non-compete agreements with our management, key employees and others. However, we cannot assure you that such existing measures are sufficient and effective. Despite these measures, any of our intellectual property rights could be challenged, invalidated, circumvented or misappropriated. In the event that we resort to litigation to enforce our intellectual property rights, such litigation could result in

31

substantial costs and a diversion of our managerial and financial resources. We can provide no assurance that we will prevail in such litigation. In addition, our trade secrets may be leaked or otherwise become available to, or be independently discovered by, our competitors. Any failure in protecting or enforcing our intellectual property rights could have a material adverse effect on our business, results of operations and financial condition.

We may face claims of intellectual property infringement and other related claims, which could be time-consuming and costly to defend and may result in an adverse impact over our operations.

We cannot assure you that our operations or any aspects of our business do not or will not infringe upon or violate intellectual property rights, including, but not limited to, trademarks, patents, copyrights, know-how, or other rights owned or held by third parties. We may also be subject to legal or administrative proceedings and claims relating to intellectual property rights or other rights of third parties in the future. If we become liable to third parties for infringing upon their intellectual property rights, we could be required to pay a substantial damage award. We may also be subject to injunctions that prohibit us from using such intellectual property rights and require us to alter our processes or methodologies, which may not be technically or commercially feasible and may cause us to expend significant resources. Any claims or litigation in this area, whether we ultimately win or lose, could be time-consuming and costly, could cause the diversion of management’s attention and resources away from the operations of our business and could damage our reputation.

Our registered or unregistered trademarks or trade names may be challenged, infringed or determined to be infringing on other marks, and we may not be able to protect our rights to these trademarks and trade names. We historically used and 秦淮数据, and currently use in China. We have filed applications for registering in China in several categories that cover our scope of business. As of the date of this prospectus, we have received one rejection of our trademark registration application in one of the categories. We are in the process of reapplying for trademark registration in such category. However, there is no assurance that we can eventually succeed in obtaining approval for the reapplication. As to the trade name and trademark that we used historically, our application to register 秦淮数据 was rejected by the relevant trademark authority due to the inclusion of a place name in China. Our application to register in one certain category was rejected by the relevant trademark authority due to similarity with certain registered trademarks. Although we can reapply at any time, we cannot assure you that such trademarks will be successfully registered in all relevant categories. A third party may adopt similar trade names or trademarks, thereby impeding our ability to build brand identity and possibly leading to market confusion. As of the date of this prospectus, we had not encountered any legal claims brought by third parties relating to infringement or violation of any intellectual property rights which may have a material adverse effect on us. However, there can be no assurance that third parties holding rights to similar trade names or trademarks would not take actions against us alleging infringement of such rights or otherwise assert their rights. On the other hand, we cannot assure you that we will succeed in bringing trademark infringement claims against third parties, especially in the case where we have not successfully registered such trademarks or have not registered in the relevant category.

If our clients’ proprietary intellectual property or confidential information is misappropriate or disclosed by us or our employees in violation of applicable laws and contractual arrangements, we could be exposed to protracted and costly legal proceedings and lose clients.

We and our employees are in some cases provided with access to our clients’ proprietary intellectual property and confidential information, including technology, software products, business policies and plans, and trade secrets. Many of our clients require that we do not engage in the unauthorized use or disclosure of such intellectual property or information and that we will be required to indemnify our clients for any loss they may suffer as a result. We use security technologies and other methods to prevent employees from making unauthorized copies, or engaging in unauthorized use or unauthorized disclosure, of such intellectual property

32

and confidential information. We also require our employees to enter into non-disclosure arrangements to limit access to and distribution of our clients’ intellectual property and other confidential information as well as our own. However, the steps taken by us in this regard may not be adequate to safeguard our clients’ intellectual property and confidential information. In addition, we may not always be aware of intellectual property registrations or applications relating to source codes, software products or other intellectual property belonging to our clients. As a result, if our clients’ proprietary rights are misappropriated by us or our employees, our clients may consider us liable for such act and seek damages and compensation from us.

Assertions of infringement of intellectual property or misappropriation of confidential information against us, if successful, could have a material adverse effect on our business, financial condition and results of operations. Protracted litigation could also result in existing or potential clients deferring or limiting their purchase or use of our services until resolution of such litigation. Even if such assertions against us are unsuccessful, they may cause us to lose existing and future business and incur reputational harm and substantial legal fees.

Significant impairment of our long-lived assets could materially impact our financial position and results of our operations

We have recorded a significant amount of long-lived assets, primarily including our property and equipment. We evaluate our long-lived assets for impairment whenever events or changes in circumstances, such as a significant adverse change to market conditions that will impact the future use of the assets, indicate that the carrying amount of an asset may not be fully recoverable. If the total of the expected undiscounted future cash flows is less than the carrying amount of the assets, an impairment loss is recognized for the difference between the fair value and carrying value of the assets. The application of long-lived asset impairment test requires significant management judgment. If our estimates and judgments are inaccurate, the fair value determined could be inaccurate and the impairment may not be adequate, and we may need to record additional impairments in the future. We recorded nil in impairment of our long-lived assets in 2018 and 2019. However, we may record impairments on long-lived assets in the future. Any impairment charge would materially adversely affect our business, financial condition and results of operations.

We have granted and may continue to grant share options and other forms of share-based incentive awards in the future, which may result in increased share-based compensation expenses.

We adopted share incentive plans for the purpose of granting share-based compensation awards to our employees and management team members to incentivize their performance and align their interests with ours. For further detailed information, please refer to “Management—Share Incentive Plan.” For the years ended December 31, 2018 and 2019 and for the six months ended June 30, 2019 and 2020, we recorded nil, RMB63.7 million (US$9.0 million), nil and RMB101.3 million (US$14.3 million), respectively, in share-based compensation expenses. We believe the granting of share-based compensation is of significant importance to our ability to attract and retain key personnel and employees, and we will continue to grant share-based compensation to employees in the future. As a result, our expenses associated with share-based compensation may increase, which may have an adverse effect on our results of operations.

We may experience impairment of goodwill in connection with our acquisition of entities or other assets.

We are required to perform an annual goodwill impairment test. As of June 30, 2020, we carried RMB466.3 million (US$66.0 million) of goodwill on our balance sheet. However, goodwill can become impaired. We test goodwill for impairment annually or more frequently if events or changes in circumstances indicate possible impairment, but the fair value estimates involved require a significant amount of difficult judgment and assumptions. We may not achieve the anticipated benefits of the acquisitions, which may result in the need to recognize impairment of some or all of the goodwill we recorded.

33

Past and future investments in and acquisitions of complementary assets and businesses may expose us to potential risks, and may result in earnings dilution and significant diversion of management attention.

We may invest in or acquire assets, technologies and businesses that are complementary to our existing business. This may include opportunities to acquire additional businesses, services, resources, or assets that are complementary to our core business. Our investments or acquisitions may not yield the results we expect. In addition, investments and acquisitions could result in the use of substantial amounts of cash, significant amortization expenses related to intangible assets, significant diversion of management attention and exposure to potential unknown liabilities of the acquired business. Moreover, the costs of identifying and consummating investments and acquisitions, and integrating the acquired businesses into ours, may be significant, and the integration of acquired businesses may be difficult or even disruptive to our existing business operations. In the event that our investments and acquisitions are not successful, our results of operations and financial condition may be materially and adversely affected.

Foreign investors are subject to requirements under Indian foreign investment laws, including Press Note 3 of 2020 issued by Department for Promotion of Industry and Internal Trade, Government of India, the interpretation and enforcement whereof may have an adverse effect on our ability to invest further in securities and capital of our Indian subsidiaries and, therefore, also on our ability to operate and maintain our business in India.

Foreign investment in Indian securities or capital of a limited liability partnership is subject to rules, regulations and policies framed by Indian regulatory authorities (namely, the Government of India and the Reserve Bank of India). In terms of Press Note 3 of 2020, dated April 17, 2020, issued by the Department for Promotion of Industry and Internal Trade, Government of India, the Consolidated FDI Policy, 2017 has been recently amended to state that all investments under the foreign direct investment route by entities of a country which shares land border with India or where the beneficial owner of an investment into India is situated in or is a citizen of any such country will require prior approval of the Government of India. Further, in the event of transfer of ownership of any existing or future foreign direct investment in an entity in India, directly or indirectly, resulting in the beneficial ownership falling within the aforesaid restriction/purview, such subsequent change in the beneficial ownership will also require approval of the Government of India. Furthermore, on April 22, 2020, the Ministry of Finance, Government of India has also made similar amendment to the Foreign Exchange Management (Non-debt Instruments) Rules, 2019. While the term “beneficial owner” is defined under the Prevention of Money-Laundering (Maintenance of Records) Rules, 2005 and the General Financial Rules, 2017, and the term “significant beneficial owner” is defined under the Companies (Significant Beneficial Owners) Rules, 2018, neither the Consolidated FDI Policy, 2017 nor the Foreign Exchange Management (Non-debt Instruments) Rules, 2019 currently provide a definition of the term “beneficial owner”. While it is possible that clarifications may come forth from the Government of India in future in this regard, there is no assurance of the same and in absence thereof, the ambiguity regarding the interpretation of “beneficial owner” under Press Note 3 of 2020 and enforcement of this regulatory change would continue. Such uncertainties may have an adverse effect on our ability to invest further in securities and capital of our Indian subsidiaries and may have implications on the transfers of ownership in the entity which fall within the purview of Press Note 3 of 2020, and therefore, also on our ability to operate and maintain our business in India. Further, there is uncertainty regarding the timeline within which the said approval from the Government of India may be obtained, if at all. Any further adverse change in the foreign investment restrictions in India may be onerous and may adversely affect our business, operations and results of operations in India.

Failure to comply with laws and regulations applicable to our business could subject us to fines and penalties and could also cause us to lose clients or otherwise harm our business.

We are subject to a variety of national, regional and local laws and regulations in the markets where we do business. These laws and regulations cover real estate, construction, telecommunication, tax, environment, labor and other government requirements, approvals, permits and licenses. If we fail to comply with these

34

requirements, we could also be subject to civil or criminal liability and the imposition of fines or other penalties. Our ability to utilize the data centers in question may also be materially and adversely affected.

Construction projects are subject to broad and strict government supervision and approval procedures in China. Under PRC laws, construction projects must receive regulatory approval from various governmental authorities prior to construction, including but not limited to project approvals and filings, construction land and project planning approvals, environment protection approvals, energy conservation review opinion, construction work commencement permit and land use right certificate. As of the date of this prospectus, five of our data center campuses are being constructed in China. A small part of regulatory approvals for these projects are still pending. According to PRC laws, construction projects needs to go through inspection and acceptance procedures with local construction authorities and receive various approvals after the completion of a project. As of the date of this prospectus, we have completed all or substantially all the inspection and acceptance procedures required for five of our hyperscale data centers currently in service in China. We have been actively taking necessary steps to complete the remaining inspection and acceptance procedures but may experience further delay, especially taking into account the COVID-19 outbreak which has slowed down regulatory approvals as the governmental authorities may need to turn their attention to more urgent needs. See “—Delays in the construction of new data centers or the expansion of existing data centers could involve significant risks to our business” and “—The outbreak of COVID-19 could disrupt our operations and construction projects and adversely affect our results of operations” for further details.

In addition, under the laws of India, there is uncertainty with respect to applicability to data centers of guidelines dated August 5, 2008 issued by Department of Telecommunications, Ministry of Communications, Government of India requiring registration of other service providers for providing IT enabled services. Imposition of such guidelines on data centers could increase our operating cost, which could in turn adversely affect our business, prospects, results of operations, cash flows and financial condition.

Failure to obtain all necessary construction project approvals and permits in a timely manner may subject us to legal sanctions, such as imposition of fines, suspension of construction or use of, rectification within a time limit, or under limited circumstances, being required to vacate from the properties in question. Any of the foregoing could have a material adverse impact on our business operation and financial conditions. In addition, we will not be able to obtain property ownership certificate until we have obtained all requisite approvals and permits for such property. Our rights as the property owner of such property may be adversely affected as a result of the absence of property ownership certificate.

Among the data centers and office spaces that we lease, certain of the lease agreements have not been registered or filed with relevant authorities in accordance with the applicable PRC laws and regulations. The enforcement of this legal requirement varies depending on local practices. In case of failure to register or file a lease, the parties to the unregistered lease may be ordered to make rectifications (which would involve registering such leases with the relevant authority) before being subject to penalties. The penalty ranges from RMB1,000 (US$141.5) to RMB10,000 (US$1,415.4) for each unregistered lease, at the discretion of the relevant authority. The law is not clear as to which of the parties, the lessor or the lessee, is liable for the failure to register the lease. In the event that a fine is determined to be imposed on the lessee, in whole or in part, we will be subject to such fine.

Any dispute or claim in relation to the titles of the properties that we occupy, including any litigation involving allegations of illegal or unauthorized use of these properties, could require us to relocate our business operations occupying these properties. If any of our leases are terminated or voided as a result of challenges from third parties or the government or if the lease is otherwise not renewed by our landlords upon expiration, we would need to seek alternative premises and incur relocation costs. We cannot assure you that we will be able to relocate such operations to suitable alternative premises, and any such relocation may result in disruption to our business operations and thereby result in loss of earnings. We may also need to incur additional costs for the relocation of our operation. There is also no assurance that we will be able to effectively mitigate the possible

35

adverse effects that may be caused by such disruption, loss or costs. Any of such disruption, loss or costs could materially and adversely affect our financial condition and results of operations.

Global economic conditions or any adverse developments in the economic, political or regulatory environment of any of the markets in which our operating properties are located or are being constructed, including China, Malaysia and India, may materially adversely affect our business and operating results.

Currently our data center facilities in service are located in China and Malaysia and there are new data center facilities under construction in China and India. Consequently, we may be exposed to greater economic risks as our business presence becomes more geographically diverse. Also, we may be susceptible to adverse developments in the economic, political and regulatory environment in any of these markets, including, but not limited to, business layoffs or downsizing, industry slowdowns, relocations of businesses, increases in taxes and costs of complying with existing or increased governmental regulation. For example, we derive a substantial portion of our revenues from our operations in China. Accordingly, our financial results have been, and are expected to continue to be, affected by the economy and the data center industry in China. While the economy in China has grown significantly over the past decades, growth has been uneven, both geographically and among various sectors of the economy, and the rate of growth has been slowing down. In addition, the United States and China have recently been involved in controversy over trade barriers in China that threatened a trade war between the countries and have implemented or proposed to implement tariffs on certain imported products. Sustained tension between the United States and China over trade policies could significantly undermine the stability of the global and Chinese economy. There have also been concerns on the relationship between China and other countries, including the surrounding Asian countries, which may potentially have economic effects. Any adverse developments in the economy or data center industry in general, or any decrease in demand for data center space resulting from adverse developments in the regulatory or business environment in China, Malaysia, India and globally could materially adversely impact our business, results of operations and financial condition.

General economic conditions and the costs and availability of capital may be adversely affected in some or all of the metropolitan areas in which we conduct our operations. Instability in the Pan-Asian and other economies and international financial markets generally may adversely affect our ability, and the ability of our clients, to meet liquidity and capital expenditure requirements and may result in adverse effects on our, and our clients’, businesses, financial condition and results of operations. Our sales cycle could also be lengthened if clients reduce spending on, or delay decision-making with respect to, our services, which could adversely affect our revenue growth and our ability to recognize revenue. We could also experience pricing pressure as a result of economic conditions if our competitors lower prices and attempt to lure away our clients with lower cost solutions. Finally, our ability to access the capital markets may be severely restricted at a time when we would like, or need, to do so, which could have an impact on our flexibility to pursue additional expansion opportunities and maintain our desired level of revenue growth in the future.

Our success depends substantially upon access to qualified personnel, including Mr. Jing Ju, Mr. Michael Foust and other senior management and senior employees. Our business operations may be harmed if we fail to recruit, train or retain qualified personnel.

Our success depends on the continued services of our senior management team and qualified key personnel, particularly Mr. Jing Ju, our founder and chief executive officer, Mr. Michael Foust, our chairman, and other executives named in this prospectus, as well as and key personnel who can provide the technical, strategic and marketing skills required for our company to grow. Although we have entered into confidentiality and non-competition agreements with our senior management team and qualified key personnel, there is no assurance that any member of our senior management team or any of our qualified key personnel will not join a competitor. In the event that any dispute arises between us, on one hand, and any of our senior management and qualified key personnel, on the other hand, we may have to incur substantial costs and expenses in order to enforce such agreements or we may be unable to enforce them at all.

36

We compete with other companies, including many of our competitors, for the limited pool of talent in these fields. Some of our competitors have greater resources than we do and may be able to offer more attractive terms of employment. We cannot provide any assurance that we will be able to retain our current executive officers or key employees. The failure to recruit and retain necessary personnel, including, but not limited to, members of our senior management and key research and development team, could harm our business and our ability to grow our company, and could adversely affect our business, financial condition and results of operations.

We are subject to anti-corruption, anti-bribery, anti-money laundering, economic sanction and similar laws, and noncompliance with such laws could subject us to criminal penalties or significant fines and harm our business and reputation.

We may be subject to anti-corruption, anti-bribery, anti-money laundering, financial and economic sanctions, and similar laws and regulations in various jurisdictions in which we conduct activities, including the U.S. Foreign Corrupt Practices Act, or FCPA, and other anti-corruption laws and regulations. The FCPA prohibits us and our officers, directors, employees, and business partners acting on our behalf, including agents, from corruptly offering, promising, authorizing, or providing anything of value to a “foreign official” for the purposes of influencing official decisions or obtaining or retaining business or otherwise obtaining favorable treatment. The FCPA also requires companies to make and keep books, records and accounts that accurately reflect transactions and dispositions of assets and to maintain a system of adequate internal accounting controls. A violation of these laws or regulations could adversely affect our business, reputation, financial condition, and results of operations.

We have direct or indirect interactions with officials and employees of government agencies and state-owned affiliated entities in the ordinary course of business. We also have business collaborations with government agencies and state-owned affiliated entities. For example, in China, we may contract with the national grid and telecommunication carriers, which are state-owned enterprises. In the countries where we have operations, we need to obtain various approvals, permits and licenses from the local or national governments. These interactions subject us to an increasing level of compliance-related concerns, and we can be held liable for the illegal activities of our employees, representatives, contractors, agents and business partners, even if we do not explicitly authorize such activities. We are in the process of implementing policies and procedures designed to ensure compliance by us and our directors, officers, employees, representatives, contractors, agents, and business partners with applicable anti-corruption, anti-bribery, anti-money laundering, financial and economic sanctions, and similar laws and regulations. However, our policies and procedures may not be sufficient and our directors, officers, employees, representatives, contractors, agents, and business partners could engage in improper conduct for which we may be held responsible. Non-compliance with anti-corruption, anti-bribery, anti-money laundering, or financial and economic sanctions laws could subject us to whistleblower complaints, adverse media coverage, investigations, and severe administrative, civil and criminal sanctions, collateral consequences, remedial measures, and legal expenses, all of which could materially and adversely affect our business, reputation, financial condition, and results of operations. In addition, responding to any enforcement action may result in the diversion of management’s attention and resources, significant defense costs and other professional fees.

We face exposure to foreign currency exchange rate fluctuations, and such fluctuations could adversely affect our business, results of operations and financial condition.

Our reporting currency is the Renminbi, and the functional currency of our subsidiaries is either their local currency or the U.S. dollar, depending on the circumstances. If the Renminbi strengthens relative to the local currencies or the U.S. dollar, our consolidated financial position and results of operations may be negatively impacted as these local currency or the U.S. dollar amounts will translate into fewer Renminbi. As a result, we are exposed to foreign currency risks related to our revenues and operating expenses denominated in currencies other than Renminbi. For additional information on foreign currency risk, see “Management’s Discussion and Analysis of Financial Condition and Results of Operations—Quantitative and Qualitative Disclosures about Market Risk.”

37

In addition, a substantial portion of our revenues and expenses are denominated in Renminbi. We are a holding company and we rely on dividends paid by our operating subsidiaries in China for our cash needs. Any significant revaluation of Renminbi may materially and adversely affect our results of operations and financial position reported in Renminbi when translated into U.S. dollars, and the value of, and any dividends payable on, the ADSs in U.S. dollars. To the extent that we need to convert U.S. dollars we receive from this offering into Renminbi for capital expenditures and working capital and other business purposes, appreciation of Renminbi against the U.S. dollar would have an adverse effect on Renminbi amount we would receive from the conversion. Conversely, if we decide to convert our Renminbi into U.S. dollars for the purpose of making payments for dividends on our ordinary shares or ADSs, strategic acquisitions or investments or other business purposes, appreciation of the U.S. dollar against Renminbi would have a negative effect on the U.S. dollar amount available to us. Further, the value of Renminbi against the U.S. dollar and other currencies is affected by changes in China’s political and economic conditions and by China’s foreign exchange policies, among other things, and our currency exchange losses may be magnified by PRC exchange control regulations that restrict our ability to convert Renminbi into foreign currency. As a result, fluctuations in exchange rates may have a material adverse effect on your investment.

If we fail to implement and maintain an effective system of internal controls to remediate our material weakness over financial reporting, we may be unable to accurately report our results of operations, meet our reporting obligations or prevent fraud, and investor confidence and the market price of the ADSs may be materially and adversely affected.

Prior to this offering, we have been a private company with limited accounting and financial reporting personnel and other resources with which we address our internal control over financial reporting. In connection with the audits of our consolidated financial statements as of December 31, 2018 and 2019 and for the years then ended, we and our independent registered public accounting firm identified a material weakness in our internal control over financial reporting. As defined in the standards established by the U.S. Public Company Accounting Oversight Board, or PCAOB, a “material weakness” is a deficiency, or combination of deficiencies, in internal control over financial reporting, such that there is a reasonable possibility that a material misstatement of the annual or interim financial statements will not be prevented or detected on a timely basis.

The material weakness identified is our company’s lack of sufficient accounting and financial reporting personnel with requisite knowledge and experience in application of U.S. GAAP and SEC rules. We are in the process of implementing a number of measures to address the material weakness. See “Management’s Discussion and Analysis of Financial Condition and Results of Operations—Internal Control Over Financial Reporting.” However, we cannot assure you that these measures may fully address the material weakness and deficiencies in our internal control over financial reporting or that we may conclude that they have been fully remediated.

Upon completion of this offering, we will become subject to the Sarbanes-Oxley Act of 2002. Section 404 of the Sarbanes-Oxley Act, or Section 404, will require that we include a report from management on the effectiveness of our internal control over financial reporting in our annual report on Form 20-F beginning with our annual report in our second annual report on Form 20-F after becoming a public company. In addition, once we cease to be an “emerging growth company” as such term is defined in the JOBS Act, our independent registered public accounting firm must attest to and report on the effectiveness of our internal control over financial reporting. Moreover, even if our management concludes that our internal control over financial reporting is effective, our independent registered public accounting firm, after conducting its own independent testing, may issue a report that is qualified if it is not satisfied with our internal controls or the level at which our controls are documented, designed, operated or reviewed, or if it interprets the relevant requirements differently from us. In addition, after we become a public company, our reporting obligations may place a significant strain on our management, operational and financial resources and systems for the foreseeable future. We may be unable to timely complete our evaluation testing and any required remediation.

38

During the course of documenting and testing our internal control procedures, in order to satisfy the requirements of Section 404, we may identify other weaknesses and deficiencies in our internal control over financial reporting. If we fail to maintain the adequacy of our internal control over financial reporting, as these standards are modified, supplemented or amended from time to time, we may not be able to conclude on an ongoing basis that we have effective internal control over financial reporting in accordance with Section 404. Generally speaking, if we fail to achieve and maintain an effective internal control environment, it could result in material misstatements in our financial statements and could also impair our ability to comply with applicable financial reporting requirements and related regulatory filings on a timely basis. As a result, our businesses, financial condition, results of operations and prospects, as well as the trading price of our ADSs, may be materially and adversely affected. Additionally, ineffective internal control over financial reporting could expose us to increased risk of fraud or misuse of corporate assets and subject us to potential delisting from the stock exchange on which we list, regulatory investigations and civil or criminal sanctions. We may also be required to restate our financial statements from prior periods.

Compliance with rules and requirements applicable to public companies may cause us to incur increased costs, which may negatively affect our results of operations.

As a public company, we will incur significant legal, accounting and other expenses that we did not incur as a private company. In addition, the Sarbanes-Oxley Act, as well as rules subsequently implemented by the SEC and the Nasdaq, have required changes in corporate governance practices of public companies. We expect these rules and regulations to increase our legal, accounting and financial compliance costs and to make certain corporate activities more time-consuming and costly. As a company with less than US$1.07 billion in revenues for our last fiscal year, we qualify as an “emerging growth company” pursuant to the JOBS Act. An emerging growth company may take advantage of specified reduced reporting and other requirements that are otherwise applicable generally to public companies. After we are no longer an “emerging growth company,” we expect to incur significant expenses and devote substantial management effort toward ensuring compliance with the requirements of Section 404 of the Sarbanes-Oxley Act of 2002 and the other rules and regulations of the SEC.

Complying with these rules and requirements may be especially difficult and costly for us because we may have difficulty locating sufficient personnel with experience and expertise relating to U.S. GAAP and U.S. public company reporting requirements, and such personnel may command higher salaries relative to what similarly experienced personnel would command in the United States. If we cannot employ sufficient personnel to ensure compliance with these rules and regulations, we may need to rely more on outside legal, accounting and financial experts, which may be expensive. In addition, we will incur additional costs associated with our public company reporting requirements. We are evaluating and monitoring developments with respect to these new rules, and we cannot predict or estimate the amount of additional costs we may incur or the timing of such costs.

In the past, shareholders of a public company often brought securities class action suits against the company following periods of instability in the market price of that company’s securities. If we were involved in a class action suit, it could divert a significant amount of our management’s attention and other resources from our business and operations, which could harm our results of operations and require us to incur significant expenses to defend the suit. Any such class action suit, whether or not successful, could harm our reputation and restrict our ability to raise capital in the future. In addition, if a claim is successfully made against us, we may be required to pay significant damages, which could have a material adverse effect on our financial condition and results of operations.

The outbreak of COVID-19 could disrupt our operations and construction projects and adversely affect our results of operations.

An outbreak of COVID-19, a respiratory illness caused by a novel coronavirus, occurred in China and worldwide in 2020. In early February 2020, the World Health Organization declared the outbreak a Public Health Emergency of International Concern. While initially the outbreak was largely concentrated in China, it has now

39

spread to a growing number of other international locations and infections have been reported globally. In an effort to limit the spread of the disease, many countries including China, Malaysia and India, have taken various emergency measures to combat the spread of the virus, including travel restrictions, voluntary and mandatory cessations of business operations, mandatory quarantines, work-from-home and other alternative working arrangements, limitations on social and public gatherings and lockdowns of cities or regions. These measures delayed the return of our employees to work, and our construction projects and obtaining certain regulatory approvals. Any prolonged deviations from normal daily operations could negatively impact our business. Due to the widespread nature and severity of COVID-19 as well as the measures taken to limit its spread, the Chinese economy may be adversely impacted in the first quarter of 2020 and beyond. Further, the spread of the COVID-19 outbreak has caused severe disruptions in the U.S. and global economy and financial markets and could potentially create widespread business continuity issues of an as-yet unknown magnitude and duration. To the extent that COVID-19 or any health epidemic harms the Chinese and global economies in general, our results of operations could be adversely affected.

We face risks related to natural disasters, health epidemics and other catastrophes, which could significantly disrupt our business, operations, liquidity and financial condition.

Our business could be materially and adversely affected by natural disasters or other catastrophes, such as earthquakes, fire, floods, hail, windstorms, severe weather conditions, environmental accidents, power loss, communications failures, explosions, terrorist attacks and similar events. Our business could also be materially and adversely affected by public health emergencies, such as the outbreak of avian influenza, severe acute respiratory syndrome, or SARS, Zika virus, Ebola virus, COVID-19 or other local health epidemics in China and worldwide. If any of our employees is suspected of having contracted any contagious disease, we may under certain circumstances be required to quarantine such employees and the affected areas of our premises. As a result, we may have to temporarily suspend part of or all our operations. Furthermore, authorities may impose restrictions on travel and transportation and implement other preventative measures in affected regions to contain a disease outbreak, which may lead to the temporary closure of our facilities and declining economic activity at large. A prolonged outbreak of any of these illness or other adverse public health developments in China or elsewhere in the world could have a material adverse effect on our business operations.

We may be adversely affected by political tensions between the United States and China.

Political tensions between the United States and China have escalated due to, among other things, trade disputes, the COVID-19 outbreak, sanctions imposed by the U.S. Department of Treasury on certain officials of the Hong Kong Special Administrative Region and the central government of the PRC and the executive orders issued by U.S. President Donald J. Trump in August 2020 that prohibit certain transactions with ByteDance Ltd., Tencent Holdings Ltd. and the respective subsidiaries of such companies. Rising political tensions could reduce levels of trades, investments, technological exchanges and other economic activities between the two major economies, which would have a material adverse effect on global economic conditions and the stability of global financial markets. Any of these factors could have a material adverse effect on our business, prospects, financial condition and results of operations. Furthermore, there have been recent media reports on deliberations within the U.S. government regarding potentially limiting or restricting China-based companies from accessing U.S. capital markets. If any legislation were to be enacted or any regulations were to be adopted along these lines, it could inhibit our ability to raise capital or jeopardize our ability to remain listed in the United States. In addition, any such legislation or regulations could negatively affect the attitudes of investors towards China-based issuers listed in the United States in general, which also could have a material and adverse impact on the trading price of our ADSs.

40

Risks Relating to Our Corporate Structure

If the PRC government deems that our contractual arrangements do not comply with PRC regulatory restrictions on foreign investment in the relevant industries, or if these regulations or the interpretation of existing regulations change in the future, we could be subject to severe penalties or be forced to relinquish our interests in those operations.

The PRC government regulates telecommunications-related businesses through strict business licensing requirements and other government regulations. These laws and regulations also include limitations on foreign ownership of PRC companies that engage in telecommunications-related businesses. Specifically, foreign investors are not allowed to own more than a 50% equity interest in any PRC company engaging in value-added telecommunications businesses, with certain exceptions relating to e-commerce which does not apply to us. Any such foreign investor must also have experience and a good track record in providing value-added telecommunications services overseas.

Because we are a Cayman Islands company, we are classified as a foreign enterprise under PRC laws and regulations, and our wholly owned PRC subsidiaries are foreign-invested enterprises, or FIEs. To comply with PRC laws and regulations, we conduct our business in China through contractual arrangements with our consolidated VIEs and their shareholders. These contractual arrangements provide us with effective control over our consolidated VIEs and enable us to receive substantially all of the economic benefits of our consolidated VIEs in consideration for the services provided by our wholly-owned PRC subsidiaries, and have an exclusive option to purchase all of the equity interest in our consolidated VIEs when permissible under PRC laws. For a description of these contractual arrangements, see “Corporate History and Structure—Contractual Arrangements with Our VIEs and Their Respective Shareholders.”

We believe that our corporate structure and contractual arrangements comply with the current applicable PRC laws and regulations. However, as there are substantial uncertainties regarding the interpretation and application of PRC laws and regulations, including the Regulations on Mergers and Acquisitions of Domestic Enterprises by Foreign Investors, or the M&A Rules, the telecommunications circular described above and the Telecommunications Regulations and the relevant regulatory measures concerning the telecommunications industry, there can be no assurance that the PRC government, such as MOFCOM or MIIT or other authorities that regulates providers of data center service and other participants in the telecommunications industry would agree that our corporate structure or any of the above contractual arrangements comply with PRC licensing, registration or other regulatory requirements, with existing policies or with requirements or policies that may be adopted in the future. PRC laws and regulations governing the validity of these contractual arrangements are uncertain and the relevant government authorities have broad discretion in interpreting these laws and regulations.

If our corporate and contractual structure is deemed by the Ministry of Industry and Information Technology, or the MIIT, or the Ministry of Commerce, or the MOFCOM, or other regulators having competent authority, to be illegal, either in whole or in part, we may lose control of our consolidated VIEs and have to modify such structure to comply with regulatory requirements. However, there can be no assurance that we can achieve this without material disruption to our business. Further, if our corporate and contractual structure is found to be in violation of any existing or future PRC laws or regulations, the relevant regulatory authorities would have broad discretion in dealing with such violations, including:

41

Any of these actions could cause significant disruption to our business operations and severely damage our reputation, which would in turn materially and adversely affect our business, financial condition and results of operations. If any of these occurrences results in our inability to direct the activities of our VIEs that most significantly impact their economic performance, and/or our failure to receive the economic benefits from our VIEs, we may not be able to consolidate the entities in our consolidated financial statements in accordance with U.S. GAAP.

Our contractual arrangements with our consolidated VIEs may result in adverse tax consequences to us.

As a result of our corporate structure and the contractual arrangements among our WFOE, our VIE, its shareholders and us, we are effectively subject to the PRC value-added tax at rates from 6% to 13% and related surcharges on revenues generated by our subsidiary from our contractual arrangements with our VIE. The PRC Enterprise Income Tax Law and its Implementing Regulations require every enterprise in China to submit its annual enterprise income tax return together with a report on transactions with its affiliates or related parties to the relevant tax authorities. According to the Implementing Regulations of the Enterprise Income Tax Law, these transactions may be subject to audit or challenge by the PRC tax authorities within ten years after the taxable year during which the transactions are conducted. We may be subject to adverse tax consequences if the PRC tax authorities were to determine that the contracts between us and our VIE were not on an arm’s length basis and therefore constitute a favorable transfer pricing arrangements. If this occurs, the PRC tax authorities could request that our VIE and any of its subsidiaries adjust their taxable income upward for PRC tax purposes. Such a pricing adjustment could adversely affect us by reducing expense deductions recorded by such VIE and thereby increasing the VIE’s tax liabilities, which could subject the VIE to late fees and other penalties for the underpayment of taxes. Our results of operations may be materially and adversely affected if our VIE’s tax liabilities increase or if either of them becomes subject to late payment fees or other penalties.

We rely on contractual arrangements with our consolidated VIEs and their shareholders for our operations in China, which may not be as effective as direct ownership in providing operational control and otherwise have a material adverse effect as to our business.

We have relied and expect to continue to rely on variable interest entity arrangements to conduct a significant part of our operations in China. We rely on contractual arrangements with our VIEs and their shareholders to conduct a significant part of our operations in China. For a description of these contractual arrangements, see “Corporate History and Structure.” The shareholders of our VIEs may not act in the best interests of our company or may not perform their obligations under these contracts. If we had direct ownership of our VIEs, we would be able to exercise our rights as a shareholder to effect changes in the board of directors of our VIEs, which in turn could implement changes, subject to any applicable fiduciary obligations, at the management and operational level. However, under the contractual arrangements, we would rely on legal remedies under PRC law for breach of contract in the event that our VIE and its shareholders did not perform their obligations under the contracts. These legal remedies may not be as effective as direct ownership in providing us with control over our consolidated VIEs.

If our consolidated VIEs or its shareholders fail to perform their obligations under the contractual arrangements, we may have to incur substantial costs and expend additional resources to enforce such arrangements. All the agreements under our contractual arrangements are governed by PRC law and provide for

42

the resolution of disputes through arbitration in China. Accordingly, these contracts would be interpreted in accordance with PRC law and any disputes would be resolved in accordance with PRC legal procedures. The legal system in the PRC is not as developed as in some other jurisdictions, such as the United States. As a result, uncertainties in the PRC legal system could limit our ability to enforce these contractual arrangements. Meanwhile, there are very few precedents and little formal guidance as to how contractual arrangements in the context of a variable interest entity should be interpreted or enforced under PRC law. There remain significant uncertainties regarding the ultimate outcome of such arbitration should legal action become necessary. In addition, under PRC law, rulings by arbitrators are final, parties cannot appeal the arbitration results in courts, and if the losing parties fail to carry out the arbitration awards within a prescribed time limit, the prevailing parties may only enforce the arbitration awards in PRC courts through arbitration award recognition proceedings, which would require additional expenses and delay. In the event we are unable to enforce these contractual arrangements, or if we suffer significant delay or other obstacles in the process of enforcing these contractual arrangements, we may not be able to exert effective control over our consolidated VIEs, and our ability to conduct our business may be negatively affected. See “—Risks Relating to Doing Business in China—Uncertainties in the interpretation and enforcement of PRC laws and regulations could limit the legal protections available to you and us.”

The registered shareholders of our VIEs may have potential conflicts of interest with us, which may materially and adversely affect our business and financial condition.

The registered shareholders of our VIEs, may have potential conflicts of interest with us. These shareholders may not remain as shareholders of our VIEs, or breach, or cause our VIEs to breach, or refuse to renew, the existing contractual arrangements we have with them and our VIEs, which would have a material and adverse effect on our ability to effectively control our VIEs and receive economic benefits from them, which may result in deconsolidation of our VIEs. For example, the shareholders may be able to cause our agreements with our VIEs to be performed in a manner adverse to us by, among other things, failing to remit payments due under the contractual arrangements to us on a timely basis. We cannot assure you that when conflicts of interest arise, any or all of these shareholders will act in the best interests of our company or such conflicts will be resolved in our favor.

Currently, we do not have any arrangements to address potential conflicts of interest between these shareholders and our company. We rely on these shareholders to abide by the laws of China, which provide that directors owe a fiduciary duty to the company that requires them to act in good faith and in what they believe to be the best interests of the company and not to use their position for personal gains. There is currently no specific and clear guidance under PRC laws that addresses any conflict between PRC laws and laws of Cayman Islands in respect of any conflict relating to corporate governance. If we cannot resolve any conflict of interest or dispute between us and the shareholders of our VIEs, we would have to rely on legal proceedings, which could result in disruption of our business and subject us to substantial uncertainty as to the outcome of any such legal proceedings.

The shareholders of our VIEs may be involved in personal disputes with third parties or other incidents that may have an adverse effect on their respective equity interests in the relevant VIEs and the validity or enforceability of our contractual arrangements with the relevant entity and its shareholders. For example, in the event that any of the shareholders of our VIEs who is married, divorces his or her spouse, the spouse may claim that the equity interest of the relevant VIE held by such shareholder is part of their community property and should be divided between such shareholder and his or her spouse. If such claim is supported by the court, the relevant equity interest may be obtained by the shareholder’s spouse or another third party who is not subject to obligations under our contractual arrangements, which could result in a loss of the effective control over the relevant VIE by us. Similarly, if any of the equity interests of our VIEs is inherited by a third party with whom the current contractual arrangements are not binding, we could lose our control over the relevant VIE or have to maintain such control by incurring unpredictable costs, which could cause significant disruption to our business and operations and harm our financial condition and results of operations.

43

Substantial uncertainties exist with respect to the interpretation and implementation of the newly enacted PRC Foreign Investment Law and its Implementation Regulations and how they may impact the viability of our current corporate structure, corporate governance, business operations and financial results.

On March 15, 2019, the National People’s Congress approved the Foreign Investment Law, which came into effect on January 1, 2020 and replaced the trio of laws regulating foreign investment in China, namely, the Sino-foreign Equity Joint Venture Enterprise Law, the Sino-foreign Cooperative Joint Venture Enterprise Law and the Wholly Foreign-invested Enterprise Law On December 26, 2019, the State Council issued the Regulations on Implementing the Foreign Investment Law of the PRC, which came into effect on January 1, 2020, and replaced the Regulations on Implementing the Sino-Foreign Equity Joint Venture Enterprise Law, Provisional Regulations on the Duration of Sino-Foreign Equity Joint Venture Enterprise Law, the Regulations on Implementing the Wholly Foreign-Invested Enterprise Law , and the Regulations on Implementing the Sino-Foreign Cooperative Joint Venture Enterprise Law. The Foreign Investment Law embodies an expected PRC regulatory trend to rationalize its foreign investment regulatory regime in line with prevailing international practice and the legislative efforts to unify the corporate legal requirements for both foreign and domestic investments. However, since it is relatively new, uncertainties still exist in relation to its interpretation and implementation. For instance, under the Foreign Investment Law, “foreign investment” refers to the investment activities directly or indirectly conducted by foreign individuals, enterprises or other entities in China but it does not explicitly stipulate the contractual arrangements as a form of foreign investment. Though these regulations do not explicitly classify contractual arrangements as a form of foreign investment, there is no assurance that foreign investment via contractual arrangements would not be interpreted as a type of indirect foreign investment activities under the definition in the future. In addition, the definition contains a catch-all provision which includes investments made by foreign investors through means stipulated in laws or administrative regulations or other methods prescribed by the State Council. Therefore, the Foreign Investment Law still leaves leeway for future laws, administrative regulations or provisions promulgated by the State Council to provide for contractual arrangements as a form of foreign investment. In any of these cases, it will be uncertain whether our contractual arrangements will be deemed to be in violation of the market access requirements for foreign investment under the PRC laws and regulations. Furthermore, if future laws, administrative regulations or provisions prescribed by the State Council mandate further actions to be taken by companies with respect to existing contractual arrangements, we may face substantial uncertainties as to whether we can complete such actions in a timely manner, or at all. Failure to take timely and appropriate measures to cope with any of these or similar regulatory compliance challenges could materially and adversely affect our current corporate structure, corporate governance and business operations.

In addition, the Foreign Investment Law further specifies that foreign investments shall be conducted in line with the negative list issued by or approved to be issued by the State Council. If an FIE proposes to conduct business in an industry subject to foreign investment “restrictions” in the “negative list”, the FIE must meet certain conditions under the “negative list” before being established. If an FIE proposes to conduct business in an industry subject to foreign investment “prohibitions” in the “negative list,” it must not engage in the business. The Special Administrative Measures for Access of Foreign Investment (Negative List) (2020 Edition), or the Negative List, which was promulgated jointly by the MOFCOM and the NDRC on June 23, 2020 and became effective on July 23, 2020, the Negative List expands the scope of industries in which foreign investment is permitted by reducing the number of industries that fall within the Negative List. Foreign investment in value- added telecommunications services (except e-commerce, domestic conferencing, store-and-forward, and call center services), including Internet data center services, still falls within the Negative List.

It is uncertain whether the industry of data center and providing value-added telecommunication services, in which our consolidated affiliated entities operate, will be subject to the foreign investment restrictions or prohibitions under the “negative list” to be issued in the future. Furthermore, if future laws, administrative regulations or provisions prescribed by the State Council mandate further actions to be taken by companies with respect to existing contractual arrangements, we may face substantial uncertainties as to whether we can complete such actions in a timely manner, or at all. Failure to take timely and appropriate measures to cope with any of these or similar regulatory compliance challenges could materially and adversely affect our current corporate structure, corporate governance and business operations.

44

Our ability to enforce the equity pledge agreements between us and the shareholders of our VIEs may be subject to limitations based on PRC laws and regulations.

Pursuant to the equity pledge agreements relating to our VIEs, shareholders of our VIEs pledged their equity interests in our VIEs to our WFOEs to secure our VIEs’ and their shareholders’ performance of the obligations and indebtedness under the Exclusive Business Cooperation Agreement, Purchase Option Agreement, Power of Attorney and Equity Pledge Agreement. As of the date of this prospectus, we have registered or are in the process of registering the equity pledges under our variable interest entity arrangements with the relevant local branch of the State Administration for Market Regulation, or the SAMR. Under the PRC Property Law, when an obligor fails to pay its debt when due, the pledgee may choose to either conclude an agreement with the pledger to obtain the pledged equity or seek payments from the proceeds of the auction or sell-off of the pledged equity. If our VIEs fail to perform their obligations secured by the pledges under the equity pledge agreements, one remedy in the event of default under the agreements is to require the pledger to sell the equity interests in our VIEs, as applicable, in an auction or private sale and remit the proceeds to our subsidiary in China, net of related taxes and expenses. Such an auction or private sale may not result in our receipt of the full value of the equity interests in our VIEs. We consider it very unlikely that the public auction process would be undertaken since, in an event of default, our preferred approach would be to ask our WFOE that is a party to the Purchase Option Agreement to designate another PRC person or entity to acquire the equity interests in such VIE and replace the existing shareholders pursuant to the Purchase Option Agreement.

In addition, in the registration forms of the local branch of the SAMR for the pledges over the equity interests under the equity pledge agreements, the amount of registered equity interests pledged to our WFOEs shall be designated as a fixed figure. The equity pledge agreements with the shareholders of our VIEs provide that the pledged equity interest constitutes continuing security for any and all of the indebtedness, obligations and liabilities of our VIEs under the relevant contractual arrangements, and therefore it is possible that the amount of registered equity interests cannot cover the secured obligation as a whole. However, there is no guarantee that a PRC court will not take the position that the amount listed on the equity pledge registration forms represents the full amount of the collateral that has been registered and perfected. If this is the case, the obligations that are supposed to be secured in the equity pledge agreements in excess of the amount listed on the equity pledge registration forms could be determined by the PRC court to be unsecured debt, which takes last priority among creditors and often does not have to be paid back at all. We do not have agreements that pledge the assets of our VIE and their subsidiaries for the benefit of us or our WFOE, although our VIE grants our WFOE options to purchase the assets of our VIE and its equity interests in its subsidiaries under the Purchase Option Agreement.

If our VIEs and their subsidiaries become the subject of a bankruptcy or liquidation proceeding, we may lose the ability to use and enjoy their assets, which could reduce the size of our operations and materially and adversely affect our business.

We do not have priority pledges and liens against the assets of our VIEs. If our VIEs undergo involuntary liquidation proceedings, third-party creditors may claim rights to some or all of their assets and we may not have priority against such third-party creditors on the assets of our VIEs. If our VIEs liquidate, we may take part in the liquidation procedures as a general creditor under the PRC Enterprise Bankruptcy Law and recover any outstanding liabilities owed by our VIEs to our WFOEs under the applicable service agreement.

If the shareholders of our VIEs were to attempt to voluntarily liquidate our VIEs without obtaining our prior consent, we could effectively prevent such unauthorized voluntary liquidation by exercising our right to request the shareholders of our VIEs to transfer all of their respective equity ownership interests to a PRC entity or an individual designated by us in accordance with the option agreement with the shareholders of our VIE. In addition, under the purchase option agreement signed by our WFOEs, our VIEs and their shareholders and according to the PRC Property Law, the shareholders of our VIEs do not have the right to issue dividends to themselves or otherwise distribute the retained earnings or other assets of our VIEs without our consent. In the event that the shareholders of our VIEs initiate a voluntary liquidation proceeding without our authorization or

45

attempts to distribute the retained earnings or assets of our VIEs without our prior consent, we may need to resort to legal proceedings to enforce the terms of the contractual arrangements. Any such litigation may be costly and may divert our management’s time and attention away from the operation of our business, and the outcome of such litigation will be uncertain.

PRC regulation of loans to and direct investment in PRC entities by offshore holding companies and governmental control of conversion of foreign currencies into Renminbi may delay or prevent us from using the proceeds of this offering to make loans to our WFOEs and VIEs or to make additional capital contributions to our PRC subsidiaries, which could materially and adversely affect our liquidity and our ability to fund and expand our business.

We are an offshore holding company conducting a significant portion of our operations in China through our WFOEs, our VIEs and their subsidiaries. We may make loans to our WFOEs, our VIEs and their subsidiaries, or we may make additional capital contributions to our WFOEs.

Any loans to our WFOEs, which are treated as Foreign Investment Enterprises, or FIEs, under PRC law, are subject to PRC regulations and foreign exchange loan registrations. For example, loans by us to our WFOEs, our VIEs and their subsidiaries to finance their activities cannot exceed statutory limits and must be registered with the local counterpart of the State Administration of Foreign Exchange, or SAFE, or filed with SAFE in its information system. We may also provide loans to our consolidated affiliated entities or other domestic PRC entities, according to the Circular of the People’s Bank of China on Matters relating to the Comprehensive Macro-prudential Management of Cross-border Financing issued by the People’s Bank of China in January 2017. According to the Notice of the People’s Bank of China and the State Administration of Foreign Exchange on Adjustments to Comprehensive Macro-prudential Regulation Parameters for Cross-border Financing issued by the People’s Bank of China and the State Administration of Foreign Exchange in March 2020, the limit for the total amount of foreign debt is 2.5 times of their respective net assets. Moreover, any medium or long-term loan to be provided by us to our consolidated affiliated entities or other domestic PRC entities must also be filed and registered with the National Development and Reform Commission, or the NDRC. We may also decide to finance our PRC subsidiaries by means of capital contributions. These capital contributions must be reported to the Ministry of Commerce, or MOFCOM, or its local counterpart.

On March 30, 2015, SAFE issued the Circular of the State Administration of Foreign Exchange on Reforming the Administrative Approach Regarding the Settlement of the Foreign Exchange Capital of Foreign-invested Enterprises, or SAFE Circular 19, which took effect and replaced previous regulations effective on June 1, 2015. Pursuant to SAFE Circular 19, up to 100% of foreign currency capital of a foreign-invested enterprise may be converted into Renminbi capital according to the actual operation, and within the business scope, of the enterprise at its will. Although SAFE Circular 19 allows for the use of Renminbi converted from the foreign currency-denominated capital for equity investments in the PRC, the restrictions continue to apply as to FIEs’ use of the converted Renminbi for purposes beyond the business scope, for entrusted loans or for inter-company Renminbi loans. On June 9, 2016, SAFE promulgated the Notice of the State Administration of Foreign Exchange on Reforming and Standardizing the Foreign Exchange Settlement Management Policy of Capital Account, or SAFE Circular 16, effective on June 9, 2016, which reiterates some rules set forth in Circular 19, but changes the prohibition against using Renminbi capital converted from foreign currency-denominated registered capital of a foreign-invested company to issue Renminbi entrusted loans to a prohibition against using such capital to issue loans to non-affiliated enterprises. On October 23, 2019, the SAFE issued the Notice of the State Administration of Foreign Exchange on Further Facilitating Cross-border Trade and Investment, which, among other things, expanded the use of foreign exchange capital to domestic equity investment area. Non-investment foreign-funded enterprises are allowed to lawfully make domestic equity investments by using their capital on the premise without violation to prevailing special administrative measures for access of foreign investments (negative list) and the authenticity and compliance with the regulations of domestic investment projects. If our VIEs require financial support from us or our wholly owned subsidiary in the future and we find it necessary to use foreign currency-denominated capital to provide such financial support, our ability to fund our VIEs’ operations will be subject to statutory limits and restrictions, including those described above.

46

In light of the various requirements imposed by PRC regulations on loans to and direct investment in PRC entities by offshore holding companies, including SAFE Circular 19, SAFE Circular 16 and other relevant rules and regulations, we cannot assure you that we will be able to complete the necessary government registrations or obtain the necessary government approvals on a timely basis, if at all, with respect to future loans by us to our WFOEs, our VIEs or their subsidiaries or with respect to future capital contributions by us to our WFOEs. If we fail to complete such registrations or obtain such approvals, our ability to use the proceeds we received from our initial public offering and to capitalize or otherwise fund our PRC operations may be negatively affected, which could materially and adversely affect our liquidity and our ability to fund and expand our business.

Risks Relating to Doing Business in China

We may fail to obtain, maintain and update licenses and permits necessary to conduct our operations in the PRC, and our business may be materially and adversely affected as a result of any changes in the laws and regulations governing the VATS industry in the PRC.

The laws and regulations regarding value-added telecommunications services, or VATS, licenses in the PRC are relatively new and are still evolving, and their interpretation and enforcement involve significant uncertainties. Investment activities in the PRC by foreign investors are principally governed by the Industry Catalog Relating to Foreign Investment, or the Catalog. The Catalog divides industries into three categories: encouraged, restricted and prohibited. Industries not included in the Catalog are permitted industries. Industries such as VATS, including Internet data center services, or IDC services, restrict foreign investment. Specifically, the Administrative Regulations on Foreign-Invested Telecommunications Enterprises restrict the ultimate capital contribution percentage held by foreign investor(s) in a foreign-invested VATS enterprise to 50% or less. Under the Telecommunications Regulations, telecommunications service providers are required to procure operating licenses prior to their commencement of operations. The Administrative Measures for Telecommunications Business Operating License, which took effect on April 10, 2009 and was amended on September 1, 2017, set forth the types of licenses required to provide telecommunications services in China and the procedures and requirements for obtaining such licenses. See “Regulations—PRC Regulations—Regulations on Value-added Telecommunication Services”.

As of the date of this prospectus, all of our companies which provide IDC services have obtained the related licenses. For example, Chindata (Beijing) Co., Ltd. obtained a cross-regional IDC license in February 2019, the scope of which now includes Beijing, Tianjin, Zhangjiakou, Datong, Shenyang, Shanghai, Wuxi, Nantong, Yangzhou, Ningbo, Jinan, Wuhan, Guangzhou, Shenzhen, Foshan, Chengdu, and Xi’an. Datong Qinling Information Science and Technology Co., Ltd. obtained a cross-regional IDC license in November 2019, the scope of which now includes Beijing, Zhangjiakou, Datong, Shanghai, Nantong, Guangzhou, and Shenzhen. Datong Sitan Data Science and Technology Co., Ltd. obtained a cross-regional IDC license in June 2019, the scope of which now includes Beijing, Zhangjiakou, Datong, Shanghai, Nantong, Guangzhou, and Shenzhen. Chindata (Shenzhen) Co., Ltd. obtained a cross-regional IDC license in October 2018, the scope of which now includes Beijing, Tianjin, Zhangjiakou, Datong, Shenyang, Shanghai, Wuxi, Nantong, Yangzhou, Ningbo, Jinan, Wuhan, Guangzhou, Shenzhen, Foshan, Chengdu, and Xi’an. Sidake Hebei Data Science and Technology Co., Ltd. obtained a cross-regional IDC license in June 2019, the scope of which now includes Beijing, Zhangjiakou, Datong, Shanghai, Nantong, Guangzhou, and Shenzhen.

There can be no assurance that we will be able to maintain our existing licenses or permits necessary to provide our current IDC services in the PRC, renew any of them when their current term expires, or update existing licenses or obtain additional licenses necessary for our future business expansion. The failure to obtain, retain, renew or update any license or permit generally, and our IDC licenses in particular, could materially and adversely disrupt our business and future expansion plans.

In addition, if future PRC laws or regulations governing the VATS industry require that we obtain additional licenses or permits or update existing licenses in order to continue to provide our IDC services, there can be no

47

assurance that we would be able to obtain such licenses or permits or update existing licenses in a timely fashion, or at all. If any of these situations occur, our business, financial condition and prospects would be materially and adversely affected.

We may rely principally on dividends and other distributions on equity paid by our WFOEs to fund any cash and financing requirements we may have, and any limitation on the ability of our WFOEs to pay dividends to us could have a material adverse effect on our ability to conduct our business.

We are a holding company, and we may rely principally on dividends and other distributions on equity paid by our WFOEs, which in turn relies on consulting and other fees paid to us by our VIEs, for our cash and financing requirements, including the funds necessary to pay dividends and other cash distributions to our shareholders and service any debt we may incur. If our WFOEs incur debt on their own behalf in the future, the instruments governing the debt may restrict their ability to pay dividends or make other distributions to us. In addition, the PRC tax authorities may require us to adjust our taxable income under the contractual arrangements our WFOEs currently have in place with our VIEs in a manner that would materially and adversely affect their ability to pay dividends and other distributions to us.

Under PRC laws and regulations, our WFOEs, as wholly foreign-owned enterprise in the PRC, may pay dividends only out of their accumulated profits as determined in accordance with PRC accounting standards and regulations. In addition, wholly foreign-owned enterprise, such as our WFOEs, is required to set aside at least 10% of its accumulated after-tax profits after making up the previous year’s accumulated losses each year, if any, to fund statutory reserve funds, until the aggregate amount of such fund reaches 50% of its registered capital. It may allocate a portion of its after-tax profits based on PRC accounting standards to discretionary reserve funds according to its shareholder’s decision. These statutory reserve funds and discretionary reserve funds are not distributable as cash dividends.

In addition, the EIT Law and its implementation rules provide that withholding tax rate of 10% will be applicable to dividends payable by PRC companies to non-PRC-resident enterprises unless otherwise exempted or reduced according to treaties or arrangements between the PRC central government and governments of other countries or regions where the non-PRC-resident enterprises are incorporated.

Any limitation on the ability of our WFOEs to pay dividends or make other distributions to us could materially and adversely limit our ability to grow, make investments or acquisitions that could be beneficial to our business, pay dividends, or otherwise fund and conduct our business.

Adverse changes in China’s economic, political and social conditions, as well as laws and government policies, may materially and adversely affect our business, financial condition, results of operations and growth prospects.

We conduct businesses in the PRC, and therefore our financial conditions and results of operations are subject to influences from PRC’s economic, political and social conditions to a great extent. The PRC economy differs from the economies of most developed countries in many aspects, including, but not limited to, the degree of government involvement, control level of corruption, control of capital investment, reinvestment control of foreign exchange, allocation of resources, growth rate and development level. Although the PRC government has implemented measures emphasizing the utilization of market forces for economic reform, the reduction of state ownership of productive assets, and the establishment of improved corporate governance in business enterprises, a substantial portion of productive assets in China is still owned by the government. In addition, the PRC government continues to play a significant role in regulating industry development by imposing industrial policies. The PRC government also exercises significant control over China’s economic growth by allocating resources, controlling payment of foreign currency-denominated obligations, setting monetary policy, regulating financial services and institutions and providing preferential treatment to particular industries or companies.

48

For approximately four decades, the PRC government has implemented economic reform measures to utilize market forces in the development of the PRC economy. We cannot predict whether changes in the PRC’s economic, political and social conditions and in its laws, regulations and policies will have any adverse effect on our current or future business, financial condition or results of operations. In addition, many of the economic reforms carried out by the PRC government are unprecedented or experimental and are expected to be refined and improved over time. This refining and improving process may not necessarily have a positive effect on our operations and business development. For example, the PRC government has in the past implemented a number of measures intended to slow down certain segments of the economy, including the real property industry, which the government believed to be overheating. These actions, as well as other actions and policies of the PRC government, could cause a decrease in the overall level of economic activity in the PRC and, in turn, have an adverse impact on our business and financial condition.

Uncertainties in the interpretation and enforcement of PRC laws and regulations could limit the legal protections available to you and us.

We conduct a substantial portion of business operations in the PRC, and our PRC subsidiaries and consolidated VIEs are subject to laws, rules and regulations applicable to foreign investment in China. The PRC legal system is a civil law system based on written statutes. Unlike the common law system, prior court decisions may be cited for reference but have limited precedential value. The PRC legal system is evolving rapidly, and the interpretation of many laws, regulations and rules may contain inconsistencies and enforcement of these laws, regulations and rules involves uncertainties.

In 1979, the PRC government began to promulgate a comprehensive system of laws, rules and regulations governing economic matters in general. The overall effect of legislation over the past four decades has significantly enhanced the protections afforded to various forms of foreign investment in China. However, China has not developed a fully integrated legal system, and recently enacted laws, rules and regulations may not sufficiently cover all aspects of economic activities in China or may be subject to significant degrees of interpretation by PRC regulatory agencies. In particular, because these laws, rules and regulations are relatively new, and because of the limited number of published decisions and the nonbinding nature of such decisions, and because the laws, rules and regulations often give the relevant regulator significant discretion in how to enforce them, the interpretation and enforcement of these laws, rules and regulations involve uncertainties and can be inconsistent and unpredictable.

From time to time, we may have to resort to administrative and court proceedings to enforce our legal rights. However, since PRC judicial and administrative authorities have significant discretion in interpreting and implementing statutory provisions and contractual terms, it may be more difficult to predict the outcome of a judicial or administrative proceeding than that in more developed jurisdictions. Furthermore, the PRC legal system is based, in part, on government policies and internal rules, some of which are not published in a timely manner, or at all, but which may have retroactive effects. As a result, we may not always be aware of any potential violation of these policies and rules. Such unpredictability towards our contractual, property (including intellectual property) and procedural rights could adversely affect our business and impede our ability to continue our operations.

Our business operations are extensively impacted by the policies and regulations of the PRC government. Any policy or regulatory change may cause us to incur significant compliance costs.

We are subject to extensive national, provincial and local governmental regulations, policies and controls. Central governmental authorities and provincial and local authorities and agencies regulate many aspects of Chinese industries, including, among others and in addition to specific industry-related regulations, the following aspects:

49

The liabilities, costs, obligations and requirements associated with these laws and regulations may be material, may delay the commencement of operations at our new data centers or cause interruptions to our operations. Failure to comply with the relevant laws and regulations in our operations may result in various penalties, including, among others the suspension of our operations and thus adversely and materially affect our business, prospects, financial condition and results of operations. Additionally, there can be no assurance that the relevant government agencies will not change such laws or regulations or impose additional or more stringent laws or regulations. Compliance with such laws or regulations may require us to incur material capital expenditures or other obligations or liabilities.

The approval of the China Securities Regulatory Commission, or the CSRC, may be required in connection with this offering under a PRC regulation.

On August 8, 2006, six PRC regulatory agencies, including the MOFCOM, the State-Owned Assets Supervision and Administration Commission, or the SASAC, the State Administration of Taxation, the State Administration for Industry and Commerce, or the SAIC, the CSRC, and the SAFE, jointly adopted the Regulations on Mergers and Acquisitions of Domestic Enterprises by Foreign Investors, or the M&A Rules, which came into effect on September 8, 2006 and were amended on June 22, 2009. The M&A Rules include, among other things, provisions that purport to require that an offshore special purpose vehicle formed for the purpose of an overseas listing of securities in a PRC company obtain the approval of the CSRC prior to the listing and trading of such special purpose vehicle’s securities on an overseas stock exchange. On September 21, 2006, the CSRC published on its official website procedures regarding its approval of overseas listings by special purpose vehicles. However, substantial uncertainty remains regarding the scope and applicability of the M&A Rules to offshore special purpose vehicles.

While the application of the M&A Rules remains unclear, we believe, based on the advice of our PRC counsel, Haiwen & Partners, that the CSRC approval is not required in the context of this offering because (i) the CSRC currently has not issued any definitive rule or interpretation concerning whether offerings like ours under this prospectus are subject to this regulation, (ii) we established the WFOEs by means of direct investment and not through a merger or acquisition of the equity or assets of a “PRC domestic company” as such term is defined under the M&A Rules; and (iii) no explicit provision in the M&A Rules classifies the contractual arrangements under the VIE Agreements as a type of acquisition transaction falling under the M&A Rules. There can be no assurance that the relevant PRC government agencies, including the CSRC, would reach the same conclusion as our PRC counsel. If the CSRC or other PRC regulatory body subsequently determines that we need to obtain the CSRC’s approval for this offering or if the CSRC or any other PRC government authorities promulgates any interpretation or implements rules before our listing that would require us to obtain CSRC or other governmental approvals for this offering, we may face adverse actions or sanctions by the CSRC or other PRC regulatory agencies. In any such event, these regulatory agencies may impose fines and penalties on our operations in China, limit our operating privileges in China, delay or restrict the repatriation of the proceeds from this offering into the PRC or take other actions that could have a material adverse effect on our business, financial condition, results of operations, reputation and prospects, as well as our ability to complete this offering. The CSRC or

50

other PRC regulatory agencies may also take actions requiring us, or making it advisable for us, to halt this offering before settlement and delivery of the ADSs offered by this prospectus. Consequently, if you engage in market trading or other activities in anticipation of and prior to settlement and delivery, you do so at the risk that such settlement and delivery may not occur.

Government control of currency conversion and future fluctuation of Renminbi exchange rates could have a material adverse effect on our results of operations and financial condition, and may reduce the value of, and dividends payable on, our Shares in foreign currency terms.

A substantial portion of our income, costs and expenses are denominated in Renminbi, which is not currently a completely freely convertible currency. A portion of these income must be converted into other currencies to meet our foreign currency obligations, including our payments of declared dividends, if any, for our Shares.

Under the PRC’s existing foreign exchange regulations, by complying with certain procedural requirements, following the completion of this Offering, we will be able to undertake current account foreign exchange transactions, including payment of dividends in foreign currencies without prior approval from the State Administration of Foreign Exchange. However, the PRC government may take measures at its discretion in the future to restrict access to foreign currencies for capital account and current account transactions under certain circumstances. We may not be able to pay dividends in foreign currencies to our Shareholders if the PRC government restricts access to foreign currencies for current account transactions. Under existing PRC foreign exchange regulations, conversion of Renminbi is permitted, without prior approval from the SAFE, for current account transactions, including profit distributions, interest payments and expenditures from trade-related transactions, as long as certain procedural requirements are complied with. However, approval from and registration with the SAFE and other PRC regulatory authorities are required where Renminbi is to be converted into foreign currency and remitted out of China for capital account transactions, which includes foreign direct investment and repayment of loans denominated in foreign currencies. These limitations could affect our ability to obtain foreign exchange through equity financing, or to obtain foreign exchange for capital expenditures.

The value of Renminbi against the U.S. dollar and other currencies fluctuate, subject to change resulting from the PRC government’s policies, and depends to a large extent on domestic and international economic and political developments as well as supply and demand in the local market. It is difficult to predict how market forces or government policies may impact the exchange rate between the Renminbi and the U.S. dollar or other currencies in the future. In addition, the PBOC regularly intervenes in the foreign exchange market to limit fluctuations in Renminbi exchange rates and achieve policy goals.

Furthermore, the net proceeds from this Offering are expected to be deposited overseas in currencies other than Renminbi until we obtain necessary approvals from relevant PRC regulatory authorities to convert these proceeds into onshore Renminbi. If the net proceeds cannot be converted into onshore Renminbi in a timely manner, our ability to deploy these proceeds efficiently may be affected, as we will not be able to invest these proceeds on RMB-denominated assets onshore or deploy them in uses onshore where Renminbi is required, which may adversely affect our business, results of operations and financial condition.

PRC regulations relating to offshore investment activities by PRC residents may limit our PRC subsidiaries’ ability to increase their registered capital or distribute profits to us or otherwise expose us or our PRC resident beneficial owners to liability and penalties under PRC law.

The SAFE promulgated the Circular on Relevant Issues Relating to PRC Resident’s Investment and Financing and Roundtrip Investment through Special Purpose Vehicles, or SAFE Circular 37, in July 2014, which replaced the previous Circular on Relevant Issues Concerning Foreign Exchange Administration for PRC Residents Engaging in Financing and Roundtrip Investments through Overseas Special Purpose Vehicles, or SAFE Circular 75. SAFE Circular 37 requires PRC residents, including PRC resident individuals and PRC

51

entities, to register with SAFE or its local branch in connection with their establishment or control of an offshore entity established for the purpose of overseas investment or financing. In addition, such PRC resident individuals must update their SAFE registrations when the offshore special purpose vehicle that such PRC resident individuals directly own the equity interests in undergoes material events relating to any change of basic information (including change of such PRC residents or entities, name and operation term), increases or decreases in investment amount, transfers or exchanges of shares, or mergers or divisions. SAFE Circular 37 also requires a PRC entity to undergo the foreign exchange registration and updating procedure in accordance with the Provisions on Foreign Exchange Administration of the Outbound Direct Investment of Domestic Institutions, issued by the SAFE in July 2009 and other relevant regulations.

On February 28, 2015, SAFE promulgated a Notice on Further Simplifying and Improving Foreign Exchange Administration Policy on Direct Investment, or SAFE Notice 13, which became effective on June 1, 2015. In accordance with SAFE Notice 13, PRC residents are required to apply for foreign exchange registration of foreign direct investment and outbound direct investment, including those required under SAFE Circular 37, with qualified banks, instead of SAFE. The qualified banks, under the supervision of SAFE, directly examine the applications and conduct the registration.

In addition, pursuant to the Measures for the Administration of Outbound Investment which was promulgated by the MOFCOM in September 2014 and became effective in October 2014, and the Administrative Measures of Outbound Investment of Enterprises which was promulgated by NDRC in December 2017 and became effective in March 2018, both of which replaced previous rules regarding outbound direct investment by PRC entities, any outbound investment of PRC enterprises is required to be approved by or filed with MOFCOM, NDRC or their local branches.

If our direct or indirect shareholders who are PRC residents do not complete their registration with the local SAFE branches or qualified banks, our PRC subsidiaries may be prohibited from distributing their profits and proceeds from any reduction in capital, share transfer or liquidation to us, and we may be restricted in our ability to contribute additional capital to our PRC subsidiaries. Moreover, failure to comply with the SAFE registration described above could result in liability under PRC laws for evasion of applicable foreign exchange restrictions.

Our founders and a number of our directors, officers and individual shareholders who indirectly hold shares in our Cayman Islands holding company and who are known to us as being PRC resident individuals, have completed the initial foreign exchange registrations in accordance with SAFE Circular 37 or SAFE Circular 75 then in effect, while some of them are in the process of applying for amendments to such registration. There is no assurance that such amendments will be completed in a timely manner, or will be completed at all.

However, we may not be informed of the identities of all the PRC residents holding direct or indirect interest in our company, nor can we compel our beneficial owners to comply with the requirements of SAFE Circular 37 and other outbound investment related regulations. As a result, we cannot assure you that all of our shareholders or beneficial owners who are PRC residents have complied with, and will in the future make or obtain any applicable registrations or approvals required by, SAFE Circular 37 and other outbound investment related regulations. Failure by such shareholders or beneficial owners to comply with SAFE Circular 37 and other outbound investment related regulations, or failure by us to amend the foreign exchange registrations of our PRC subsidiaries, could subject us or our shareholders to fines or legal sanctions, restrict our overseas or cross-border investment activities, limit our PRC subsidiaries’ ability to make distributions or pay dividends to us or affect our ownership structure, which could adversely affect our business and prospects.

Failure to comply with PRC regulations regarding the registration requirements for employee share ownership plans or share option plans may subject the PRC plan participants or us to fines and other legal or administrative sanctions.

Pursuant to the Notice on Issues Concerning the Foreign Exchange Administration for Domestic Individuals Participating in Stock Incentive Plan of Overseas Publicly Listed Company, issued by SAFE in February 2012,

52

employees, directors, supervisors and other senior management participating in any stock incentive plan of an overseas publicly listed company who are PRC citizens or who are non-PRC citizens residing in China for a continuous period of not less than one year, subject to a few exceptions, are required to register with SAFE through a domestic qualified agent, which could be a PRC subsidiaries of such overseas listed company, and complete certain other procedures. We and our directors, executive officers and other employees who are PRC citizens or who reside in the PRC for a continuous period of not less than one year and who have been granted restricted shares, restricted share units or options will be subject to these regulations if those employees exercise such restricted shares, restricted share units or options. Separately, SAFE Circular 37 also requires certain registration procedures to be completed if those employees exercise restricted shares, restricted share units or options before listing. Failure to complete the SAFE registrations may subject them to fines and legal sanctions and may also limit our ability to contribute additional capital into our wholly foreign-owned subsidiaries in China and limit these subsidiaries’ ability to distribute dividends to us. We also face regulatory uncertainties that could restrict our ability to adopt additional incentive plans for our directors and employees under PRC law.

In addition, the State Administration of Taxation, or the SAT has issued certain circulars concerning employee share options or restricted shares. Under these circulars, the employees working in the PRC who exercise share options or are granted restricted share units will be subject to PRC individual income tax. Our WFOEs have obligations to file documents related to employee share options or restricted shares with relevant tax authorities and to withhold individual income taxes of those employees who exercise their share options. If our employees fail to pay or we fail to withhold their income taxes according to relevant laws and regulations, we may face sanctions imposed by the tax authorities or other PRC government authorities.

Failure to make adequate contributions to various employee benefit plans as required by PRC regulations may subject us to penalties.

Companies operating in China are required to participate in various government-mandated employee benefit contribution plans, including certain social insurance, housing funds and other welfare plans, open and register accounts for social insurance accounts and housing funds, and contribute in their own names to the plans in amounts equal to certain percentages of salaries, including bonuses and allowances, of employees up to a maximum amount specified by the local government from time to time at locations where companies operate our businesses. The requirements of employee benefit contribution plans have not been implemented consistently by the local governments in China given the different levels of economic development in different geographical areas.

As of the date of this prospectus, certain of our PRC subsidiaries failed to open and register the accounts for social insurance and housing funds, and entrust third-party agencies to pay social insurance and housing provident fund for some of our employees. We may be required to make up the contributions for these welfare plans as well as late fees and fines. If we are subject to investigations or penalties related to non-compliance with labor laws, our business, financial condition and results of operations could be adversely affected.

The enforcement of the Labor Contract Law of the People’s Republic of China, or the PRC Labor Contract Law, and other labor-related regulations in the PRC may increase our labor costs, impose limitations on our labor practices and adversely affect our business and our results of operations.

On June 29, 2007, the Standing Committee of the National People’s Congress of China enacted the PRC Labor Contract Law, which became effective on January 1, 2008 and was amended on December 28, 2012. The PRC Labor Contract Law introduces specific provisions related to fixed-term employment contracts, part-time employment, probation, consultation with labor unions and employee assemblies, employment without a written contract, dismissal of employees, severance, and collective bargaining, which together represent enhanced enforcement of labor laws and regulations. According to the PRC Labor Contract Law, an employer is obliged to sign an unfixed-term labor contract with any employee who has worked for the employer for 10 consecutive years. Further, if an employee requests or agrees to renew a fixed-term labor contract that has already been

53

entered into twice consecutively, the resulting contract must have an unfixed term, with certain exceptions. The employer must pay economic compensation to an employee where a labor contract is terminated or expires in accordance with the PRC Labor Contract Law, except for certain situations which are specifically regulated. In addition, the government has issued various labor-related regulations to further protect the rights of employees. According to such laws and regulations, employees are entitled to annual leave ranging from five to 15 days and are able to be compensated for any untaken annual leave days in the amount of three times their daily salary, subject to certain exceptions. In the event that we decide to change our employment or labor practices, the PRC Labor Contract Law and its implementation rules may also limit our ability to effect those changes in a manner that we believe to be cost-effective. In addition, as the interpretation and implementation of these new regulations are still evolving, our employment practices may not be at all times deemed in compliance with the new regulations. If we are subject to severe penalties or incur significant liabilities in connection with labor disputes or investigations, our business and financial conditions may be adversely affected.

Inflation and increases in labor costs in China could negatively affect our profitability and growth.

The economy in China has experienced increases in inflation and labor costs in recent years. As a result, average wages in the PRC are expected to continue to increase. In addition, we are required by PRC laws and regulations to pay various statutory employee benefits, including pension, housing fund, medical insurance, work-related injury insurance, unemployment insurance and maternity insurance to designated government agencies for the benefit of our employees. The relevant government agencies may examine whether an employer has made adequate payments to the statutory employee benefits, and those employers who fail to make adequate payments may be subject to late payment fees, fines and/or other penalties. We expect that our labor costs, including wages and employee benefits, will continue to increase. Unless we are able to control our labor costs or pass on these increased labor costs to our users by increasing the fees for our services, our financial condition and results of operations may be adversely affected. In addition, we work with third-party contractors to carry out construction projects who face similar challenges of rising labor costs, such as the required payment of the statutory employee benefits for their employees. This can lead to them passing on their increased labor costs to us and we may have to pay more for their services.

It may be difficult to effect service of process upon us, our directors or our executive officers that reside in China or to enforce any judgments obtained from non-PRC courts or bring actions against them or us in China.

Certain of our directors and most of our executive officers reside in China. In addition, most of our assets and those of our directors and executive officers are located in China. The PRC does not have treaties providing for the reciprocal recognition and enforcement of judgments of courts with the United States, the United Kingdom, Japan and many other jurisdictions. As a result, it may not be possible for investors to serve process upon us or those persons in China, or to enforce against us or them in China, any judgments obtained from non-PRC jurisdictions.

On July 14, 2006, the Supreme People’s Court of China and the Government of the Hong Kong Special Administrative Region signed an Arrangement on Reciprocal Recognition and Enforcement of Judgments in Civil and Commercial Matters, or the 2006 Arrangement. Under such arrangement, where any designated People’s Court or any designated Hong Kong court has made an enforceable final judgment requiring payment of money in a civil and commercial case pursuant to a choice of court agreement, any party concerned may apply to the relevant People’s Court or Hong Kong court for recognition and enforcement of the judgment. On January 18, 2019, the Supreme Court of the People’s Republic of China and the Department of Justice under the Government of the Hong Kong Special Administrative Region signed the Arrangement on Reciprocal Recognition and Enforcement of Judgments in Civil and Commercial Matters by the Courts of the Mainland and of the Hong Kong Special Administrative Region, or the 2019 Arrangement. The 2019 Arrangement, for the reciprocal recognition and enforcement of judgments in civil and commercial matters between the courts in mainland China and those in the Hong Kong Special Administrative Region, stipulates the scope and particulars

54

of judgments, the procedures and ways of the application for recognition or enforcement, the review of the jurisdiction of the court that issued the original judgment, the circumstances where the recognition and enforcement of a judgment shall be refused, and the approaches towards remedies, among others. After a judicial interpretation has been promulgated by the Supreme People’s Court and the relevant procedures have been completed by the Hong Kong Special Administrative Region, both sides shall announce a date on which the 2019 Arrangement shall come into effect. The 2019 Arrangement shall apply to any judgment made on or after its effective date by the courts of both sides. The 2006 Arrangement shall be terminated on the same day when the 2019 Arrangement comes into effect. If a “written choice of court agreement” has been signed by parties according to the 2006 Arrangement prior to the effective date of the 2019 Arrangement, the 2006 Arrangement shall still apply. Although the 2019 Arrangement has been signed, its effective date has yet to be announced. Therefore, there are still uncertainties about the outcomes and effectiveness of enforcement or recognition of judgments under the 2019 Arrangement.

Shareholder claims that are common in the United States, including securities law class actions and fraud claims, generally are difficult to pursue as a matter of law or practicality in China. For example, in China, there are significant legal and other obstacles to obtaining information needed for shareholder investigations or litigation outside China or otherwise with respect to foreign entities. Although the local authorities in China may establish a regulatory cooperation mechanism with the securities regulatory authorities of another country or region to implement cross-border supervision and administration, such regulatory cooperation with the securities regulatory authorities in the United States has not been efficient in the absence of mutual and practical cooperation mechanism. According to Article 177 of the PRC Securities Law which became effective in March 2020, no overseas securities regulator is allowed to directly conduct investigation or evidence collection activities within the PRC. Accordingly, without the consent of the competent PRC securities regulators or other relevant authorities, no entity or individual may provide any documents and materials relating to securities business activities to foreign entities or government agencies. See also “—Risks Relating to Our ADSs and This Offering—You may face difficulties in protecting your interests, and your ability to protect your rights through U.S. courts may be limited, because we are incorporated under Cayman Islands law” for risks associated with investing in us as a Cayman Islands company.

China’s M&A Rules and certain other PRC regulations establish complex procedures for some acquisitions of PRC companies by foreign investors, which could make it more difficult for us to pursue growth through acquisitions in China.

A number of PRC laws and regulations have established procedures and requirements that could make merger and acquisition activities in China by foreign investors more time consuming and complex. In addition to the Anti-monopoly Law itself, these include the Regulations on Mergers and Acquisitions of Domestic Enterprises by Foreign Investors, or the M&A Rules, adopted by six PRC regulatory agencies in 2006 and amended in 2009, and the Rules of the Ministry of Commerce on Implementation of Security Review System of Mergers and Acquisitions of Domestic Enterprises by Foreign Investors, or the Security Review Rules, promulgated in 2011. These laws and regulations impose requirements in some instances that the Ministry of Commerce be notified in advance of any change-of-control transaction in which a foreign investor takes control of a PRC domestic enterprise. In addition, the Anti-Monopoly Law requires that the Ministry of Commerce be notified in advance of any concentration of undertaking if certain thresholds are triggered. Moreover, the Security Review Rules specify that mergers and acquisitions by foreign investors that raise “national defense and security” concerns and mergers and acquisitions through which foreign investors may acquire de facto control over domestic enterprises that raise “national security” concerns are subject to strict review by the Ministry of Commerce, and prohibit any attempt to bypass a security review, including by structuring the transaction through a proxy or contractual control arrangement. In the future, we may grow our business by acquiring complementary businesses. Complying with the requirements of the relevant regulations to complete such transactions could be time consuming, and any required approval processes, including approval from the Ministry of Commerce, may delay or inhibit our ability to complete such transactions, which could affect our ability to expand our business or maintain our market share.

55

We face uncertainties with respect to indirect transfers of equity interests in PRC resident enterprises by their non-PRC holding companies.

We face uncertainties regarding the reporting on and consequences of previous private equity financing transactions involving the transfer and exchange of shares in our company by non-resident investors.

In February 2015, the SAT issued the Bulletin on Issues of Enterprise Income Tax on Indirect Transfers of Assets by Non-PRC Resident Enterprises, or SAT Bulletin 7, as amended in 2017. Pursuant to this bulletin, an “indirect transfer” of assets, including equity interests in a PRC resident enterprise, by non-PRC resident enterprises may be re-characterized and treated as a direct transfer of PRC taxable assets, if such arrangement does not have a reasonable commercial purpose and was established for the purpose of avoiding payment of PRC enterprise income tax. As a result, gains derived from such indirect transfer may be subject to PRC enterprise income tax. According to SAT Bulletin 7, “PRC taxable assets” include assets attributed to an establishment in China, immovable properties located in China, and equity investments in PRC resident enterprises, in respect of which gains from their transfer by a direct holder, being a non-PRC resident enterprise, would be subject to PRC enterprise income taxes. When determining whether there is a “reasonable commercial purpose” of the transaction arrangement, features to be taken into consideration include: whether the main value of the equity interest of the relevant offshore enterprise derives from PRC taxable assets; whether the assets of the relevant offshore enterprise mainly consist of direct or indirect investment in China or if its income mainly derives from China; whether the offshore enterprise and its subsidiary directly or indirectly holding PRC taxable assets have real commercial nature which is evidenced by their actual function and risk exposure; the duration of existence of shareholders, the business model and organizational structure; the information about the payment of due income tax outside China on indirect transfer of Chinese taxable property; the substitutability between indirect investment by equity transferor, indirect transfer of Chinese taxable property and direct investment, direct transfer of Chinese taxable property; Chinese tax conventions or arrangements applicable to the proceeds from indirect transfer of Chinese taxable property; and other relevant factors. In respect of an indirect offshore transfer of assets of a PRC establishment, the resulting gain is to be included with the enterprise income tax filing of the PRC establishment or place of business being transferred, and would consequently be subject to PRC enterprise income tax at a rate of 25%. Where the underlying transfer relates to the immovable properties located in China or to equity investments in a PRC resident enterprise, which is not related to a PRC establishment or place of business of a non-resident enterprise, a PRC enterprise income tax of 10% would apply, subject to available preferential tax treatment under applicable tax treaties or similar arrangements, and the party who is obligated to make the transfer payments has the withholding obligation. SAT Bulletin 7 does not apply to transactions of sale of shares by investors through a public stock exchange where such shares were acquired from a transaction through a public stock exchange. Furthermore, Notice of SAT on Issuing the Working Rules on the Enterprise Income Tax on Income from the Indirect Transfer of Assets by Non-Resident Enterprises (for Trial Implementation), or Circular 68, which became effective on May 13, 2015, built up a special tax adjustment case management system on indirect transaction. In accordance with Circular 68, both parties to the indirect transaction shall report the transfer to the competent tax authority and submit relevant materials. In the case where an indirect transfer is considered as an indirect transfer with unreasonable commercial purposes, the transfer in question shall be reviewed and examined by the provincial tax authorities level by level.

On October 17, 2017, the SAT issued the Announcement of the State Administration of Taxation on Issues Concerning the Withholding of Non-resident Enterprise Income Tax at Source, or SAT Bulletin 37, which came into effect on December 1, 2017. The SAT Bulletin 37 further clarifies the practice and procedure of the withholding of non-resident enterprise income tax.

We face uncertainties as to the reporting and other implications of certain past and future transactions where PRC taxable assets are involved, such as offshore restructuring, sale of the shares in our offshore subsidiaries or investments. Our company may be subject to filing obligations or taxed if our company is transferor in such transactions, and may be subject to withholding obligations if our company is transferee in such transactions under SAT Bulletin 7, Circular 68 and/or SAT Bulletin 37. For transfer of shares in our company by investors that are non-PRC resident enterprises, our WFOEs may be requested to assist in the filing under SAT Bulletin 7, Circular 68 and/or SAT Bulletin 37. As a result, we may be required to expend valuable resources to comply with

56

SAT Bulletin 7, Circular 68 and/or SAT Bulletin 37 or to request the relevant transferors from whom we purchase taxable assets to comply with these circulars, or to establish that our company should not be taxed under these circulars, which may have a material adverse effect on our financial condition and results of operations.

If we are classified as a PRC resident enterprise for PRC income tax purposes, such classification could result in unfavorable tax consequences to us and our non-PRC shareholders or ADS holders.

Prior to January 1, 2008, dividends payable to non-PRC investors were exempted from withholding tax. The PRC Enterprise Income Tax Law and its implementation rules provide that PRC enterprise income tax at the rate of 10% will generally be applicable to dividends derived from sources within the PRC and received by non-PRC enterprise shareholders. Similarly, gains derived from the transfer of shares by such shareholders are also subject to PRC enterprise income tax if such gains are regarded as income derived from sources within the PRC. Since there remain uncertainties regarding the interpretation and implementation of the PRC Enterprise Income Tax Law and its implementation rules, it is uncertain whether, if we are regarded as a PRC resident enterprise, any dividends to be distributed by us to our non-PRC shareholders and ADS holders which are enterprises would be subject to any PRC withholding tax. If we are required under the PRC Enterprise Income Tax Law to withhold PRC income tax on our dividends payable to our non-PRC enterprise shareholders and ADS holders, or if gains on the disposition of our shares by such holders are subject to the EIT Law, your investment in our ordinary shares or ADSs may be materially and adversely affected.

We may be treated as a resident enterprise for PRC tax purposes under the PRC Enterprise Income Tax Law, and we may therefore be subject to PRC income tax on our global income.

Under the PRC Enterprise Income Tax Law and its implementing rules, enterprises established under the laws of jurisdictions outside of China with “de facto management bodies” located in China may be considered PRC tax resident enterprises for tax purposes and may be subject to the PRC enterprise income tax at the rate of 25% on their global income. “De facto management body” refers to a managing body that exercises substantive and overall management and control over the production and business, personnel, accounting books and assets of an enterprise. The State Administration of Taxation issued the Notice Regarding the Determination of Chinese-Controlled Offshore-Incorporated Enterprises as PRC Tax Resident Enterprises on the Basis of De Facto Management Bodies, or Circular 82, on April 22, 2009, which was partially amended by Circular 9 promulgated in January 2014. Circular 82 provides certain specific criteria for determining whether the “de facto management body” of a Chinese-controlled offshore-incorporated enterprise is located in China. Under Circular 82, a foreign enterprise is considered a PRC resident enterprise if all of the following apply: (1) the senior management and core management departments in charge of daily operations are located mainly within China; (2) decisions relating to the enterprise’s financial and human resource matters are made or subject to approval by organizations or personnel in China; (3) the enterprise’s primary assets, accounting books and records, company seals, and board and shareholders’ meeting minutes are located or maintained in China; and (4) 50% or more of voting board members or senior executives of the enterprise habitually reside in China. Further to Circular 82, the SAT issued the Public Announcement of State Administration of Taxation on Promulgation of the Administrative Measures on Income Tax on Overseas Registered Chinese-funded Holding Resident Enterprises (Trial Implementation), known as Bulletin 45, which took effect in September 2011 and amended on June 1, 2015, October 1, 2016 and June 15, 2018, to provide more guidance on the implementation of SAT Circular 82 and clarify the reporting and filing obligations of such “Chinese-controlled offshore incorporated resident enterprises.” Bulletin 45 provides procedures and administrative details for the determination of resident status and administration on post-determination matters. Although Circular 82 and Bulletin 45 only applies to offshore enterprises controlled by PRC enterprises, not those controlled by foreign enterprises or individuals, the determining criteria set forth in Circular 82 and Bulletin 45 may reflect the State Administration of Taxation’s general position on how the “de facto management body” test should be applied in determining the tax resident status of offshore enterprises in general. There have been no official implementation rules regarding the determination of the “de facto management bodies” for foreign enterprises not controlled by PRC enterprises

57

(including companies like ourselves). Therefore, it remains unclear how the tax authorities will treat a case such as ours. However, if the PRC authorities were to subsequently determine, or any future regulation provides, that we should be treated as a PRC resident enterprise, we would be subject to PRC enterprise income tax at the rate of 25% on our global income. In such case, our profitability and cash flow may be materially reduced as a result of our global income being taxed under the Enterprise Income Tax Law. We believe that none of our entities outside of China is a PRC resident enterprise for PRC tax purposes. However, the tax resident status of an enterprise is subject to determination by the PRC tax authorities and uncertainties remain with respect to the interpretation of the term “de facto management body.”

We may not be able to obtain certain benefits under the relevant tax treaty on dividends paid by our PRC subsidiary to us through our Hong Kong subsidiary.

We are a holding company incorporated under the laws of the Cayman Islands and as such rely on dividends and other distributions on equity from our PRC subsidiary to satisfy part of our liquidity requirements. Pursuant to the PRC Enterprise Income Tax Law, a withholding tax rate of 10% currently applies to dividends paid by a PRC “resident enterprise” to a foreign enterprise investor, unless any such foreign investor’s jurisdiction of incorporation has a tax treaty with China that provides for preferential tax treatment. Pursuant to the Arrangement between Mainland China and the Hong Kong Special Administrative Region for the Avoidance of Double Taxation and Prevention of Fiscal Evasion with Respect to Taxes on Income, or the Double Tax Avoidance Arrangement, such withholding tax rate may be lowered to 5% if a Hong Kong resident enterprise owns no less than 25% of a PRC enterprise. However, the 5% withholding tax rate does not automatically apply and certain requirements must be satisfied, including without limitation that (a) the Hong Kong enterprise must be the beneficial owner of the relevant dividends; and (b) the Hong Kong enterprise must directly hold no less than 25% share ownership in the PRC enterprise during the 12 consecutive months preceding its receipt of the dividends.

If the custodians or authorized users of controlling non-tangible assets of our company, including our corporate chops and seals, fail to fulfill their responsibilities, or misappropriate or misuse these assets, our business and operations could be materially and adversely affected.

Under PRC law, legal documents for corporate transactions, including contracts such as consulting service agreements we enter into with wealth management product providers, which are important to our business, are executed using the chops (a Chinese stamp or seal) or seals of the signing entity, or with the signature of a legal representative whose designation is registered and filed with the relevant branch of the SAMR.

Although we usually utilize chops to enter into contracts, the designated legal representatives of each of our WFOEs and consolidated entities have the power to enter into contracts on behalf of such entities without chops and bind such entities. In order to maintain the physical security of our chops and the chops of our PRC entities, we generally store these items in secured locations accessible only by the authorized personnel of each of our WFOEs and consolidated entities. Although we monitor such authorized personnel, there is no assurance such procedures will prevent all instances of abuse or negligence. Accordingly, if any of our authorized personnel misuse or misappropriate our corporate chops or seals, we could encounter difficulties in maintaining control over the relevant entities and experience significant disruption to our operations. If a designated legal representative obtains control of the chops in an effort to obtain control over any of our WFOEs or consolidated entities, we, our WFOEs or consolidated entities would need to pass a new shareholder or board resolution to designate a new legal representative and we would need to take legal actions to seek the return of the chops, apply for new chops with the relevant authorities, or otherwise seek legal redress for the violation of the representative’s fiduciary duties to us, which could involve significant time and resources and divert management attention away from our regular business. In addition, the affected entity may not be able to recover corporate assets that are sold or transferred out of our control in the event of such a misappropriation if a transferee relies on the apparent authority of the representative and acts in good faith.

58

The audit report included in this prospectus is prepared by an auditor who is not inspected by the Public Company Accounting Oversight Board and, as such, you are deprived of the benefits of such inspection.

Auditors of companies that are registered with the United States Securities and Exchange Commission, and traded publicly in the United States, including our independent registered public accounting firm, must be registered with the Public Company Accounting Oversight Board, or the PCAOB, and are required by the laws of the United States to undergo regular inspections by the PCAOB to assess their compliance with the laws of the United States and professional standards. Because we have substantial operations within the PRC and the PCAOB is currently unable to conduct inspections of the work of our auditors as it relates to those operations without the approval of the Chinese authorities, our auditor’s work related to our operations in China is not currently inspected by the PCAOB.

This lack of PCAOB inspections of audit work performed in China prevents the PCAOB from regularly and fully evaluating audit work of any auditors that was performed in China, including that performed by our independent registered public accounting firm. As a result, investors may be deprived of the full benefits of PCAOB inspections.

As part of a continued regulatory focus in the United States on access to audit and other information currently protected by national law, in particular China’s, in June 2019, a bipartisan group of lawmakers introduced bills in both houses of Congress that would require the SEC to maintain a list of issuers for which the PCAOB is not able to inspect or investigate an auditor report issued by a foreign public accounting firm. The Ensuring Quality Information and Transparency for Abroad-Based Listings on our Exchanges (EQUITABLE) Act prescribes increased disclosure requirements for such issuers and, beginning in 2025, the delisting from national securities exchanges such as Nasdaq of issuers included for three consecutive years on the SEC’s list. On May 20, 2020, the U.S. Senate passed S. 945, the Holding Foreign Companies Accountable Act. If passed by the U.S. House of Representatives and signed by the U.S. president, the bill would amend the Sarbanes-Oxley Act of 2002 to direct the SEC to prohibit securities of any registrant from being listed on any of the U.S. securities exchanges or trade “over-the-counter” if the auditor of the registrant’s financial statements is not subject to PCAOB inspection for three consecutive years after the law becomes effective. Enactment of any such legislation or other efforts to increase U.S. regulatory access to audit information could cause investor uncertainty for affected issuers, including us, and the market price of our ADSs could be adversely affected, and we could be delisted if we are unable to cure the situation to meet the PCAOB inspection requirement in time. It is unclear if and when any such proposed legislation will be enacted.

In addition, on June 4, 2020, U.S. President Donald J. Trump issued a memorandum ordering the President’s Working Group on Financial Markets, or the PWG, to submit a report to the President within 60 days of the memorandum that includes recommendations for actions that can be taken by the executive branch and by the SEC or PCAOB on Chinese companies listed on U.S. stock exchanges and their audit firms, in an effort to protect investors in the U.S. On August 6, 2020, the PWG released a report recommending that the SEC take steps to implement the five recommendations outlined in the report. In particular, to address companies from non-cooperating jurisdictions that do not provide the PCAOB with sufficient access to fulfill its statutory mandate, or NCJs, including China, the PWG recommends enhanced listing standards on U.S. stock exchanges. This would require, as a condition to initial and continued exchange listing, PCAOB access to work papers of the principal audit firm for the audit of the listed company. Companies unable to satisfy this standard as a result of governmental restrictions on access to audit work papers and practices in NCJs may satisfy this standard by providing a co-audit from an audit firm with comparable resources and experience where the PCAOB determines it has sufficient access to audit work papers and practices to conduct an appropriate inspection of the co-audit firm. The report permits the new listing standards to provide for a transition period until January 1, 2022 for listed companies, but would apply immediately to new listings once the necessary rulemakings and/or standard-setting are effective. After we are listed on the Nasdaq, if we fail to meet the new listing standards before the deadline specified thereunder due to factors beyond our control, we could face possible de-listing from the Nasdaq, deregistration from the SEC and/or other risks, which may materially and adversely affect, or effectively terminate, our ADS trading in the United States.

59

The inability of the PCAOB to conduct inspections of audit work performed in China makes it more difficult to evaluate the effectiveness of our auditor’s audit procedures as compared to auditors in other jurisdictions that are subject to PCAOB inspections on all of their work. Investors may lose confidence in our reported financial information and procedures and the quality of our financial statements.

Proceedings instituted recently by the SEC against certain PRC-based accounting firms, including our independent registered public accounting firm, could result in financial statements being determined to not be in compliance with the requirements of the Exchange Act.

Starting in 2011, the “big four” PRC-based accounting firms (including our independent registered public accounting firm) were affected by a conflict between U.S. and Chinese law. Specifically, for certain U.S. listed companies operating and audited in China, the SEC and the PCAOB sought to obtain from the PRC firms access to their audit work papers and related documents. The firms were, however, advised and directed that under the PRC law they could not respond directly to the U.S. regulators on those requests, and that requests by foreign regulators for access to such papers in China had to be channeled through the CSRC.

In late 2012, this impasse led the SEC to commence administrative proceedings under Rule 102(e) of its Rules of Practice and also under the Sarbanes-Oxley Act of 2002 against the Chinese accounting firms, (including our independent registered public accounting firm). A first instance trial of the proceedings in July 2013 in the SEC’s internal administrative court resulted in an adverse judgment against the firms. The administrative law judge proposed penalties on the firms including a temporary suspension of their right to practice before the SEC, although that proposed penalty did not take effect pending review by the SEC. On February 6, 2015, before SEC’s review had taken place, the firms reached a settlement with the SEC. The settlement required the firms to follow detailed procedures to seek to provide the SEC with access to PRC accounting firms’ audit documents via the CSRC. If they failed to meet specified criteria, the SEC retained the authority to impose a variety of additional remedial measures on the firms depending on the nature of the failure.

Under the terms of the settlement, the underlying proceeding against the four China-based accounting firms was deemed dismissed with prejudice four years after entry of the settlement. The four-year mark occurred on February 6, 2019. We cannot predict if the SEC will further challenge the four China-based accounting firms’ compliance with U.S. law in connection with U.S. regulatory requests for audit work papers or if the results of such a challenge would result in the SEC imposing penalties such as suspensions. If additional remedial measures are imposed on the “big four” PRC-based accounting firms, including our independent registered public accounting firm, we could be unable to timely file future financial statements in compliance with the requirements of the Exchange Act.

In the event that the “big four” PRC-based accounting firm become subject to additional legal challenges by the SEC or PCAOB, listed companies in the United States with major PRC operations may find it difficult or impossible to retain auditors in respect of their operations in China, which could result in financial statements being determined to not be in compliance with the requirements of the Exchange Act, including possible delisting. Moreover, any negative news about any such future proceedings against these audit firms may cause investor uncertainties regarding PRC-based, United States-listed companies and the market price of our ADSs may be adversely affected.

If our independent registered public accounting firm were denied, even temporarily, the ability to practice before the SEC and we were unable to timely find another registered public accounting firm to audit and issue an opinion on our financial statements, our financial statements could be determined not to be in compliance with the requirements of the Exchange Act. Such a determination could ultimately lead to the delisting of our ordinary shares from the Nasdaq or deregistration from the SEC, or both, which would substantially reduce or effectively terminate the trading of our ADSs in the United States.

60

Risks Relating to Our ADSs and This Offering

There has been no previous public market for our ADSs prior to this offering, and you may not be able to resell our ADSs at or above the price you paid, or at all.

Prior to this initial public offering, there has been no public market for our ordinary shares or ADSs. The ADSs have been approved for listing on the Nasdaq. Our ordinary shares will not be listed on any exchange or quoted for trading on any over-the-counter trading system. If an active trading market for our ADSs does not develop after this offering, the market price and liquidity of our ADSs will be materially and adversely affected.

The initial public offering price for our ADSs was determined by negotiation between us and the underwriters, which may bear no relationship to their market price after the initial public offering. We cannot assure you that an active trading market for our ADSs will develop or that the market price of our ADSs will not decline below the initial public offering price.

The trading price of our ADSs is likely to be volatile, which could result in substantial losses to investors.

The trading price of our ADSs may be volatile and could fluctuate widely due to factors beyond our control. This may happen because of broad market and industry factors, including the performance and fluctuation of the market prices of other companies with business operations located mainly in China that have listed their securities in the United States. The securities of some of these companies have experienced significant volatility since their initial public offerings, including, in some cases, substantial price declines in the trading prices of their securities. The trading performances of other Chinese companies’ securities after their offerings, including Internet and technology companies, may affect the attitudes of investors toward Chinese companies listed in the United States, which consequently may impact the trading performance of our ADSs, regardless of our actual operating performance. In addition, any negative news or perceptions about inadequate corporate governance practices or fraudulent accounting, corporate structure or matters of other Chinese companies may also negatively affect the attitudes of investors towards Chinese companies in general, including us, regardless of whether we have conducted any inappropriate activities. In addition, securities markets may from time to time experience significant price and volume fluctuations that are not related to our operating performance, such as the large decline in share prices in the United States, China and other jurisdictions in late 2008, early 2009, the second half of 2011, 2015 and the first half of 2020, which may have a material and adverse effect on the trading price of our ADSs.

In addition to market and industry factors, the price and trading volume for our ADSs may be volatile for factors specific to our own operations, including the following:

61

Any of these factors may result in large and sudden changes in the trading volume and price of the ADSs.

In the past, shareholders of public companies have often brought securities class action suits against those companies following periods of instability in the market price of their securities. If we were involved in a class action suit, it could divert a significant amount of our management’s attention and other resources from our business and operations and require us to incur significant expenses to defend the suit, which could harm our results of operations. Any such class action suit, whether or not successful, could harm our reputation and restrict our ability to raise capital in the future. In addition, if a claim is successfully made against us, we may be required to pay significant damages, which could have a material adverse effect on our financial condition and results of operations.

If securities or industry analysts do not publish or publish inaccurate or unfavorable research about our business, or if they adversely change their recommendations regarding our ADSs, the market price for our ADSs and trading volume could decline.

The trading market for the ADSs will be influenced by research or reports that industry or securities analysts publish about our business. If one or more analysts who cover us downgrade the ADSs, the market price for the ADSs would likely decline. If one or more of these analysts cease to cover us or fail to regularly publish reports on us, we could lose visibility in the financial markets, which, in turn, could cause the market price or trading volume for the ADSs to decline.

Our proposed dual-class structure with voting rights will limit your ability to influence corporate matters and could discourage others from pursuing any change of control transactions that holders of our Class A ordinary shares and the ADSs may view as beneficial.

Our authorized share capital will be divided into Class A ordinary shares and Class B ordinary shares immediately prior to the completion of this offering. In respect of matters requiring the votes of shareholders, holders of Class A ordinary shares will be entitled to one vote per share, while holders of Class B ordinary shares will be entitled to 15 votes per share based on our proposed dual-class share structure. We will sell Class A ordinary shares represented by the ADSs in this offering.

Immediately prior to the completion of this offering, Bain Capital Entities and Mr. Jing Ju, will beneficially own all of our issued Class B ordinary shares, representing             % of the aggregate voting power of our total issued and outstanding share capital immediately after the completion of this offering due to the disparate voting powers associated with our dual-class share structure, assuming the underwriters do not exercise their over-allotment option. See “Principal [and Selling] Shareholders.” After this offering, Bain Capital Entities and Mr. Jing Ju will have considerable influence over matters requiring shareholder approval, such as electing directors and approving material mergers, acquisitions, or other business combination transactions. This concentration of voting power may discourage, delay, or prevent a change of control of our company, which

62

could have the effect of depriving our other shareholders of the opportunity to receive a premium for their shares as part of a sale of our company and may reduce the price of our ADSs. This concentrated control will limit your ability to influence corporate matters and could discourage others from pursuing any potential merger, takeover, or other change of control transactions that holders of Class A ordinary shares and ADSs may view as beneficial.

Each Class B ordinary share is convertible into one Class A ordinary share at any time by the holder thereof, while Class A ordinary shares are not convertible into Class B ordinary shares under any circumstances. Upon any transfer of any Class B ordinary shares by a holder hereof to any person who is not any of BCPE Bridge Cayman, L.P., BCPE Stack Holdings, L.P., Mr. Jing Ju or their respective affiliates, such Class B ordinary Shares shall be automatically and immediately converted into an equal number of Class A ordinary Shares. In addition, pursuant to our post-offering memorandum and articles of association, all of the Class B ordinary shares held by certain Bain Capital Entities (namely, BCPE Bridge Cayman, L.P. and BCPE Stack Holdings, L.P.) shall be automatically and immediately converted into an equal number of Class A ordinary shares on the earlier of (i) such date when the number of ordinary shares held by them and their affiliates (taken as a whole) falls below 10% of our aggregate number of ordinary shares then outstanding and (ii) five years from the date of this offering. The conversion of Class B ordinary shares to Class A ordinary shares will have the effect, over time, of increasing the relative voting power of those holders of Class B ordinary shares who retain their shares in the long term. In the event that the Class B ordinary shares held by such Bain Capital Entities convert into Class A ordinary shares, the relative voting power of Mr. Jing Ju through his holding of our remaining outstanding Class B ordinary shares will increase. Furthermore, we may not qualify for a “controlled company” as defined under the Nasdaq Stock Market Rules if the total voting power owned by Bain Capital Entities falls below 50%. As a result, we may not be able to rely on certain exemptions from corporate governance requirements.

Our dual-class voting structure may render the ADSs representing our Class A ordinary shares ineligible for inclusion in certain stock market indices, and thus adversely affect the trading price and liquidity of the ADSs.

We cannot predict whether our dual-class share structure with different voting rights will result in a lower or more volatile market price of the ADSs, in adverse publicity, or other adverse consequences. Certain index providers have announced restrictions on including companies with multi-class share structures in certain of their indices. For example, S&P Dow Jones and FTSE Russell have changed their eligibility criteria for inclusion of shares of public companies on certain indices, including the S&P 500, to exclude companies with multiple classes of shares and companies whose public shareholders hold no more than 5% of total voting power from being added to such indices. As a result, our dual-class voting structure may prevent the inclusion of the ADSs representing our Class A ordinary shares in such indices, which could adversely affect the trading price and liquidity of the ADSs representing our Class A ordinary shares. In addition, several shareholder advisory firms have announced their opposition to the use of multiple class structure and our dual-class structure may cause shareholder advisory firms to publish negative commentary about our corporate governance, in which case the market price and liquidity of the ADSs could be adversely affected.

Techniques employed by short sellers may drive down the market price of our ADSs.

Short selling is the practice of selling securities that the seller does not own but rather has borrowed from a third party with the intention of buying identical securities back at a later date to return to the lender. The short seller hopes to profit from a decline in the value of the securities between the sale of the borrowed securities and the purchase of the replacement shares, as the short seller expects to pay less in that purchase than it received in the sale. As it is in the short seller’s best interests for the price of the stock to decline, many short sellers publish, or arrange for the publication of, negative opinions regarding the relevant issuer and its business prospects in order to create negative market momentum and generate profits for themselves after selling a stock short. These short attacks have, in the past, led to selling of shares in the market.

Public companies, including those have a substantial portion of their operations in China have been the subject of short selling. Much of the scrutiny and negative publicity has centered on allegations of a lack of

63

effective internal control over financial reporting resulting in financial and accounting irregularities and mistakes, inadequate corporate governance policies or a lack of adherence thereto and, in many cases, allegations of fraud. As a result, many of these companies are now conducting internal and external investigations into the allegations and, in the interim, are subject to shareholder lawsuits and/or SEC enforcement actions.

It is not clear what effect such negative publicity could have on us. If we were to become the subject of any unfavorable allegations, whether such allegations are proven to be true or untrue, we could have to expend a significant amount of resources to investigate such allegations and/or defend ourselves. While we would strongly defend against any such short seller attacks, we may be constrained in the manner in which it can proceed against the relevant short seller by principles of freedom of speech, applicable state law or issues of commercial confidentiality. Such a situation could be costly and time-consuming, and could distract our management from growing our business. Even if such allegations are ultimately proven to be groundless, allegations against us could severely impact its business operations and stockholders equity, and any investment in our ADSs could be greatly reduced or rendered worthless.

The sale or availability for sale of substantial amounts of our ADSs could adversely affect their market price.

Sales of substantial amounts of our ADSs in the public market after the completion of this offering, or the perception that these sales could occur, could adversely affect the market price of our ADSs and could materially impair our ability to raise capital through equity offerings in the future. The ADSs sold in this offering will be freely tradable without restriction or further registration under the Securities Act of 1933, as amended, or the Securities Act, and shares held by our existing shareholders may also be sold in the public market in the future subject to the restrictions in Rule 144 and Rule 701 under the Securities Act and the applicable lock-up agreements. There will be                ADSs (equivalent to                 Class A ordinary shares) outstanding immediately after this offering, or ADSs (equivalent to                 Class A ordinary shares) assuming that the underwriters’ option to purchase additional ADSs is exercised in full. In connection with this offering, we, our officers, directors, existing shareholders and all holders of share incentive awards have agreed not to sell any of our ordinary shares or our ADSs or are otherwise subject to similar lockup restrictions for                days after the date of this prospectus without the prior written consent of the representatives of the underwriters, subject to certain exceptions. However, the underwriters may release these securities from these restrictions at any time, subject to applicable regulations of the Financial Industry Regulatory Authority, Inc. We cannot predict what effect, if any, market sales of securities held by our significant shareholders or any other shareholder or the availability of these securities for future sale will have on the market price of our ADSs. See “Underwriting” and “Shares Eligible for Future Sale” for a more detailed description of the restrictions on selling our securities after this offering.

Participation in this offering by certain investors may significantly reduce the liquidity of our ADSs.